Drainage Act, R.S.O. 1990, c. D.17, Drainage Act
Drainage Act
R.S.O. 1990, CHAPTER D.17
Historical version for the period August 20, 2007 to December 14, 2009.
Last amendment: 2006, c. 35, Sched. C, s. 27.
CONTENTS
Definitions | |
Mutual agreement re drainage works | |
Drainage works constructed on requisition | |
Petition | |
Drainage works constructed on petition | |
Notice that environmental appraisal is required | |
Benefit cost statement | |
Appointment of engineer | |
Determination of petition compliance | |
Preliminary report | |
Duties of engineer | |
Power to enter on lands | |
Duties re survey | |
Providing capacity for covered drainage works | |
Sufficient outlet | |
Report re disposal of material taken from drainage works | |
Bridges and culverts on roads | |
Construction of bridges, etc. | |
Engineer may recommend abandonment of drain | |
Continuing drainage works beyond limits of municipality | |
Engineer to distinguish assessments | |
Assessment for benefit | |
Assessment for liability | |
Assessment for special benefit | |
Engineer may assess a block, etc. | |
Increased cost, how borne | |
Assessment where drainage works continued beyond limits of municipality | |
Assessing lands in neighbouring municipality | |
Allowances for right of way, etc. | |
Amount for damage to ornamental trees, etc. | |
Allowance for existing drains | |
Allowance for damage due to insufficient outlet | |
Allowance for loss of access | |
Prior assessments to be taken into consideration | |
Assessment may be shown in money | |
Assessment of affected land | |
Engineer to assess separately | |
Variation in assessments for maintenance and repair | |
Time for filing report | |
Engineer’s finding, drainage works not required, etc. | |
Notice of drainage works | |
Consideration of report | |
Liability of original petitioners | |
Sufficiency of petition | |
Adoption of report | |
Notice of court of revision to be sent to local municipalities and to owners | |
Appeal from report to referee | |
Appeal to Tribunal | |
Appeal by conservation authority | |
Appeal by municipality | |
Powers of Tribunal | |
Appeals | |
Adjournment of court or Tribunal | |
Appeal to Tribunal | |
Evidence by engineer | |
Clerk to alter assessments | |
Referral back to engineer | |
By-law may be passed | |
Meeting to consider contract price | |
Municipalities required to raise cost | |
Imposition of special assessment | |
Amendment of by-law | |
Powers of contractor | |
Appeal by owner of land | |
Subsequent subdivision of land | |
Subsequent connections with drainage works | |
Tenant’s covenant to pay taxes, when to include drainage assessments | |
Registration of by-law | |
Public utility or road authority, option to construct drainage works | |
Fees of engineer part of cost | |
Account of engineer | |
Review by Tribunal | |
Costs to be deemed part of cost of drainage works | |
Maintenance of drainage works and cost | |
Service of copy of by-law on municipality liable for contribution and appeal from by-law | |
Varying original assessments for maintenance | |
Deepening, widening or extending without report of engineer | |
Improving, upon examination and report of engineer | |
Power to compel repairs | |
Person responsible for obstruction to remove it on notice | |
Removal of minor obstructions | |
Municipality may sue for cost of damage to drainage works | |
Pollution of drains prohibited | |
Abandonment of all or part of drainage works | |
Provincial grants | |
When grants not to be made | |
Payment of grant | |
Application for grant | |
Distribution | |
Reduction of grant | |
Director | |
Persons to advise and assist | |
Appointment of drainage superintendent | |
Inspection of drainage works | |
Appointment of commissioner | |
Offence | |
Court of revision | |
Tribunal | |
Proceeding commenced by notice | |
Extension of time | |
Decision final | |
Appointment of referee | |
Notice of time and place of hearing | |
Clerk of court | |
Sheriffs, etc., to assist referee | |
Powers of referee | |
Referee may make rules | |
Assessment of costs | |
Costs in discretion of referee | |
Tariff of costs | |
Proceedings instituted by notice | |
Affidavits filed before motion | |
Extension of time for appeal | |
When referee proceeds on view | |
Clerk to forward notice of filing | |
Copy of decision to be sent to Minister and municipality | |
Amendment of by-law | |
Assessing of costs payable | |
Transfer to other court | |
Actions may be transferred to referee | |
Appeal from decision of referee | |
Interprovincial drainage works, from Ontario into adjoining province | |
Initiation of drainage works in unorganized territory | |
Authorization of emergency work | |
Regulations |
Definitions
“benefit” means the advantages to any lands, roads, buildings or other structures from the construction, improvement, repair or maintenance of a drainage works such as will result in a higher market value or increased crop production or improved appearance or better control of surface or subsurface water, or any other advantages relating to the betterment of lands, roads, buildings or other structures; (“avantage”)
“benefit cost statement” means a statement relating the anticipated benefits expressed in dollars to the total estimated cost of the drainage works; (“état coût-avantages”)
“built-up area” means an area of land where,
(a) not less than 50 per cent of the frontage upon one side of a road for a distance of not less than 200 metres is occupied by dwellings, buildings used for business purposes, schools or churches, or
(b) not less than 50 per cent of the frontage upon both sides of a road for a distance of not less than 100 metres is occupied by dwellings, buildings used for business purposes, schools or churches, or
(c) not more than 200 metres of a road separates any land described in clause (a) or (b) from any other land described in clause (a) or (b), or
(d) a plan of subdivision has been registered; (“agglomération”)
“commissioner” means a commissioner appointed by a municipality by by-law; (“commissaire”)
“conservation authority” means a conservation authority established under the Conservation Authorities Act; (“office de protection de la nature”)
“court of revision” means a court of revision constituted under this Act; (“tribunal de révision”)
“Director” means the Director appointed for the purposes of this Act; (“directeur”)
“drainage superintendent” means a drainage superintendent appointed by a municipality by by-law; (“directeur des installations de drainage”)
“drainage works” includes a drain constructed by any means, including the improving of a natural watercourse, and includes works necessary to regulate the water table or water level within or on any lands or to regulate the level of the waters of a drain, reservoir, lake or pond, and includes a dam, embankment, wall, protective works or any combination thereof; (“installations de drainage”)
“engineer” means an engineer registered under the Professional Engineers Act or a surveyor registered under the Surveyors Act, or a partnership, association of persons or corporation that holds a certificate of authorization under the Professional Engineers Act or the Surveyors Act, as the case may be; (“ingénieur”)
“improvement” means any modification of or addition to a drainage works intended to increase the effectiveness of the system; (“amélioration”)
“initiating municipality” means the local municipality undertaking the construction, improvement, repair or maintenance of a drainage works to which this Act applies; (“municipalité initiatrice”)
“injuring liability” means the part of the cost of the construction, improvement, maintenance or repair of a drainage works required to relieve the owners of any land or road from liability for injury caused by water artificially made to flow from such land or road upon any other land or road; (“responsabilité des dommages”)
“lateral drain” means a drain that is designed for the drainage of one property and that begins and ends on the same property; (“drain latéral”)
“maintenance” means the preservation of a drainage works; (“entretien”)
“Minister” means the Minister of Agriculture and Food; (“ministre”)
“outlet liability” means the part of the cost of the construction, improvement or maintenance of a drainage works that is required to provide such outlet or improved outlet; (“responsabilité de la sortie”)
“owner” includes a guardian of property and a guardian, executor, administrator or trustee in whom land is vested; (“propriétaire”)
“preliminary report” means an engineer’s report containing the information specified in section 10; (“rapport préliminaire”)
“property” means a parcel of land that by the Assessment Act is required to be separately assessed; (“propriété”)
“public utility” means a person having jurisdiction over any water works, gas works, electric heat, light and power works, telegraph and telephone lines, railways however operated, street railways and works for the transmission of gas, oil, water or electrical power or energy, or any similar works supplying the general public with necessaries or conveniences; (“services publics”)
“referee” means the referee appointed under this Act; (“arbitre”)
“repair” means the restoration of a drainage works to its original condition; (“réparation”)
“report” means an engineer’s report containing the information specified in section 8; (“rapport”)
“road authority” means a body having jurisdiction and control of a common and public highway or road, or any part thereof, including a street, bridge and any other structure incidental thereto and any part thereof; (“office de la voirie”)
“special benefit” means any additional work or feature included in the construction, repair or improvement of a drainage works that has no effect on the functioning of the drainage works; (“avantage particulier”)
“sufficient outlet” means a point at which water can be discharged safely so that it will do no damage to lands or roads; (“sortie appropriée”)
“Tribunal” means the Agriculture, Food and Rural Affairs Appeal Tribunal continued under the Ministry of Agriculture, Food and Rural Affairs Act. (“Tribunal”) R.S.O. 1990, c. D.17, s. 1; 1992, c. 32, s. 8; 1999, c. 12, Sched. A, s. 9 (1); 2002, c. 17, Sched. F, Table.
Mutual agreement re drainage works
2. (1) When two or more owners of land desire to construct or improve a drainage works on any of their lands and are willing to pay the cost thereof, they may enter into a written agreement for the construction, improvement, financing and maintenance of such drainage works, which shall include the following:
1. A reference to the Drainage Act.
2. Descriptions of the lands of the parties to the agreement sufficient for the purposes of registration in the proper land registry office.
3. The estimated cost of the drainage works.
4. A description of the drainage works, including its nature and approximate location.
5. The proportion of the cost of the construction, improvement and maintenance of the drainage works that is to be borne by each of the owners of the lands.
6. The date the agreement was entered into.
7. An affidavit of a subscribing witness to the execution of the agreement by the parties sufficient for the purposes of registration in the proper land registry office. R.S.O. 1990, c. D.17, s. 2 (1).
Filing of agreement
(2) A copy of the agreement and the plans and schedules, if any, of the proposed drainage works may be filed with the clerk of the local municipality in which the land or any part thereof is situate, and the agreement or an executed copy thereof may be registered in the proper land registry office. R.S.O. 1990, c. D.17, s. 2 (2).
Registered agreement binding on successors
(3) An agreement made under this section shall, upon registration in the proper land registry office of the agreement or an executed copy thereof, be binding upon the heirs, executors, administrators, successors and assigns of each party to the agreement. R.S.O. 1990, c. D.17, s. 2 (3).
Exception
(4) The subsequent provisions of this Act do not apply to any drainage works constructed under this section. R.S.O. 1990, c. D.17, s. 2 (4).
Drainage works constructed on requisition
3. (1) Where it is necessary, for the proper drainage of any lands, that a drainage works should be constructed thereon or constructed thereon and through the land of one or more adjacent owners, the owner of the land requiring or to be benefited by such drainage may file with the clerk of the local municipality in which the land is situate a requisition in the form prescribed by the regulations requesting that an engineer be appointed. R.S.O. 1990, c. D.17, s. 3 (1).
Deposit for expenses
(2) Upon filing the requisition, the owner shall deposit with the clerk of the municipality the sum of $300 to be used toward defraying the expenses incurred consequent thereon, which sum shall be taken into consideration by the engineer in apportioning costs. R.S.O. 1990, c. D.17, s. 3 (2).
Limit of cost
(3) No drainage works, the total estimated cost of which will exceed $7,500, shall be constructed under this section. R.S.O. 1990, c. D.17, s. 3 (3).
Cost not included
(4) For the purposes of calculating the total estimated cost in subsection (3), the cost of crossing lands occupied by the works of a public utility or road authority shall not be included. R.S.O. 1990, c. D.17, s. 3 (4).
Limit of area to be assessed
(5) Only lands lying within 750 metres from the sides of the drainage works and land lying within 750 metres from the upstream point of commencement of the drainage works may be assessed under this section. R.S.O. 1990, c. D.17, s. 3 (5).
Duty of council
(6) The council of the local municipality, upon the filing of the requisition, shall by by-law or resolution appoint an engineer to make an examination of the area and to make a preliminary report. R.S.O. 1990, c. D.17, s. 3 (6).
Notice of examination
(7) The engineer shall, before making an examination and report, cause the clerk of the local municipality to send to each owner of land and to each public utility that may be affected by such drainage works as set out in the requisition at least seven days written notice in the form prescribed by the regulations by prepaid mail, addressed to each such owner at the owner’s address as shown by the last revised assessment roll, of the date, time and place of an on-site meeting with the engineer to examine the area. R.S.O. 1990, c. D.17, s. 3 (7).
Statements
(8) The engineer shall file with the preliminary report a benefit cost statement and a statement of the anticipated effects of the drainage works on the local environment. R.S.O. 1990, c. D.17, s. 3 (8).
Engineer to set out requirements
(9) The engineer in the preliminary report shall set out the requirements for a petition sufficient to comply with section 4. R.S.O. 1990, c. D.17, s. 3 (9).
Duty of council
(10) Upon the filing of the engineer’s preliminary report, the council of the local municipality shall cause the clerk to send by prepaid mail to each owner of lands to be affected by the drainage works as set out in the requisition and to the Minister, a notice stating the name or other designation of the drainage works and the date of the council meeting at which the preliminary report will be considered. R.S.O. 1990, c. D.17, s. 3 (10).
Copy of report, etc.
(11) A copy of the preliminary report, the benefit cost statement and the statement of the anticipated effect on the local environment must accompany each notice sent under subsection (10). R.S.O. 1990, c. D.17, s. 3 (11).
Duty of clerk
(12) Unless the owner who filed the requisition files with the clerk of the local municipality a petition sufficient to comply with section 4 within sixty days of the meeting at which the report was considered, the clerk shall send, by prepaid mail, to such owner, notice that unless the requisition is withdrawn or a petition is filed within thirty days from the date the notice was sent, the council of the local municipality shall instruct the engineer to prepare a report. R.S.O. 1990, c. D.17, s. 3 (12).
Power of council
(13) Where a petition sufficient to comply with section 4 is filed within the time limits prescribed by subsection (12), the council of the local municipality shall proceed in the manner prescribed for a petition under section 4. R.S.O. 1990, c. D.17, s. 3 (13).
Duty of council
(14) Unless the requisition is withdrawn or a petition is filed with the council of the local municipality within the time limits prescribed by subsection (12), the council by by-law or resolution shall instruct the engineer to prepare a report. R.S.O. 1990, c. D.17, s. 3 (14).
Idem
(15) Despite any other provision of this Act, upon the filing of the report, unless the requisition is withdrawn, the council of the local municipality shall, subject to any appeal that may be taken, adopt the report and proceed to implement it in accordance with this Act. R.S.O. 1990, c. D.17, s. 3 (15).
Appeals
(16) Upon the filing of a report, an appeal lies therefrom to the Tribunal and as nearly as may be possible in the same manner and on the same grounds as in the case of a report for the construction of a drainage works commenced by petition under section 4. R.S.O. 1990, c. D.17, s. 3 (16); 2006, c. 19, Sched. A, s. 6 (1).
Collection of expenses
(17) Where the requisition is withdrawn or the drainage works is not proceeded with under requisition as a result of an appeal, the owner who filed the requisition is chargeable with and liable to the municipality for the expenses incurred by the municipality in connection with the requisition, and the sum with which such owner is chargeable shall be entered upon the collector’s roll for the municipality against the lands of the owner, and shall be collected in the same manner as real property taxes. R.S.O. 1990, c. D.17, s. 3 (17).
Existing ditches
(18) Every ditch constructed under The Ditches and Watercourses Act, being chapter 109 of the Revised Statutes of Ontario, 1960, shall be maintained in accordance with the award of the engineer providing for such maintenance until such ditch is brought under the provisions of this Act by requisition in the manner prescribed by subsection (1) or by petition as set out in section 4. R.S.O. 1990, c. D.17, s. 3 (18).
Petition
4. (1) A petition for the drainage by means of a drainage works of an area requiring drainage as described in the petition may be filed with the clerk of the local municipality in which the area is situate by,
(a) the majority in number of the owners, as shown by the last revised assessment roll of lands in the area, including the owners of any roads in the area;
(b) the owner or owners, as shown by the last revised assessment roll, of lands in the area representing at least 60 per cent of the hectarage in the area;
(c) where a drainage works is required for a road or part thereof, the engineer, road superintendent or person having jurisdiction over such road or part, despite subsection 61 (5);
(d) where a drainage works is required for the drainage of lands used for agricultural purposes, the Director. R.S.O. 1990, c. D.17, s. 4 (1).
Form of petition
(2) A petition under subsection (1) shall be in the form prescribed by the regulations and, where it is filed by an owner or owners under clause (1) (a) or (b), shall be signed by such owner or owners. R.S.O. 1990, c. D.17, s. 4 (2).
Petition where area lies on each side of boundary line
(3) Where it is desired to construct a drainage works for the drainage of an area composed of lands or roads lying on each side of a boundary line between two or more local municipalities, the council of any of them may proceed upon a petition as required by this Act in all respects, including the sending of notices, as if such area were entirely within the limits of the municipality. R.S.O. 1990, c. D.17, s. 4 (3).
Person deemed owner
(4) Where a person who is the owner of land, but does not appear by the last revised assessment roll of the municipality to be the owner, is a petitioner, the person shall be deemed an owner if the person’s ownership is proved to the satisfaction of the clerk, and, if the person who appears by the assessment roll to be the owner is a petitioner, the person’s name shall be disregarded in determining the sufficiency of the petition. R.S.O. 1990, c. D.17, s. 4 (4).
Persons jointly assessed
(5) Where two or more persons are jointly assessed for a property, in determining the sufficiency of a petition, they shall be deemed to be one owner. R.S.O. 1990, c. D.17, s. 4 (5).
Drainage works constructed on petition
5. (1) Where a petition in accordance with section 4 has been filed, the council shall forthwith consider the petition and shall, within thirty days after the filing of the petition,
(a) if it decides not to proceed with the drainage works, give written notice of its decision to each petitioner; or
(b) if it decides to proceed with the drainage works, give written notice of the petition and of its decision to each petitioner, the clerk of each local municipality that may be affected, and the conservation authority that has jurisdiction over any lands in the area or, if no such conservation authority exists, the Minister of Natural Resources. R.S.O. 1990, c. D.17, s. 5 (1).
Appeal to Tribunal
(2) Where a petitioner,
(a) receives notice under clause (1) (a) of a decision of the council not to proceed with the drainage works; or
(b) has not, within thirty days after the filing of the petition, received notice of a decision of the council,
the petitioner may appeal to the Tribunal or, where lands used for agricultural purposes are included in the area described in the petition, the Minister may refer the matter to the Tribunal, and the Tribunal may confirm the decision of the council or direct the council to make such decision and to take such action as the council is authorized to take under this Act and as the Tribunal considers proper. R.S.O. 1990, c. D.17, s. 5 (2); 2006, c. 19, Sched. A, s. 6 (1).
Notice that environmental appraisal is required
6. (1) Upon receipt of a notice from the initiating municipality under subsection 5 (1), a local municipality, conservation authority or the Minister of Natural Resources, as the case may be, may send to the council of the initiating municipality within thirty days a notice that an environmental appraisal of the effects of the drainage works on the area is required, and the cost thereof shall be paid by the party who requested it. R.S.O. 1990, c. D.17, s. 6 (1).
Authorization for environmental appraisal
(2) The council of the initiating municipality may obtain an environmental appraisal on its own initiative, the cost of which shall be paid by the municipality from its general funds. R.S.O. 1990, c. D.17, s. 6 (2).
Appeal
(3) The party requesting the environmental appraisal or the council of the initiating municipality, as the case may be, within forty days of receiving the account therefor, may appeal to the Tribunal, and the Tribunal may confirm or vary the account as it considers proper. R.S.O. 1990, c. D.17, s. 6 (3); 2006, c. 19, Sched. A, s. 6 (2).
Benefit cost statement
7. (1) The council of any local municipality to which notice was given under subsection 5 (1) or the Minister may send to the council of the initiating municipality within thirty days a notice that a benefit cost statement is required and the cost of preparing such statement shall be paid by the party who required it. R.S.O. 1990, c. D.17, s. 7 (1).
Idem
(2) The council of the initiating municipality may obtain a benefit cost statement on its own initiative, the cost of which shall be paid by the municipality from its general funds. R.S.O. 1990, c. D.17, s. 7 (2).
Appointment of engineer
8. (1) Where the council of the initiating municipality has decided to proceed with the drainage works described in a petition, the council shall by by-law or resolution appoint an engineer to make an examination of the area requiring drainage as described in the petition and to prepare a report which shall include,
(a) plans, profiles and specifications of the drainage works, including a description of the area requiring drainage;
(b) an estimate of the total cost thereof;
(c) an assessment of the amount or proportion of the cost of the works to be assessed against every parcel of land and road for benefit, outlet liability and injuring liability;
(d) allowances, if any, to be paid to the owners of land affected by the drainage works; and
(e) such other matters as are provided for under this Act. R.S.O. 1990, c. D.17, s. 8 (1).
Where engineer is a corporation, etc.
(2) Where the engineer appointed under this Act is a corporation, association or partnership, the appointee shall, within ten days of the date of appointment, notify the council of the name of the individual engineer who will have charge of the project and who will remain in charge until the report is filed and if for any reason the designated engineer ceases to be employed by the appointee, the appointee shall within ten days of such time notify the council of the name of his or her replacement. R.S.O. 1990, c. D.17, s. 8 (2).
Appeal or referral to Tribunal
(3) Where the council fails to appoint an engineer within sixty days after giving notice of its decision to proceed, any petitioner may appeal to the Tribunal or, where the petition was signed by the Director or where lands used for agricultural purposes are included in the area to be drained, the Minister may refer the matter to the Tribunal, and the Tribunal may direct the council to take such action as the council is authorized to take under this Act and as the Tribunal considers proper. R.S.O. 1990, c. D.17, s. 8 (3); 2006, c. 19, Sched. A, s. 6 (1).
One report on two or more petitions
(4) The council of the initiating municipality may instruct the engineer to make one report with respect to two or more petitions requiring drainage in two or more adjoining areas that require drainage. R.S.O. 1990, c. D.17, s. 8 (4).
Determination of petition compliance
9. (1) The engineer shall, before making an examination and report, cause the clerk of the local municipality to send at least seven days written notice in the form prescribed by the regulations to each owner of lands within the area requiring drainage as described in the petition and to each public utility that may be affected by the petition setting out the time and place of an on-site meeting with the engineer to examine the area. R.S.O. 1990, c. D.17, s. 9 (1).
Duty of engineer
(2) At the on-site meeting, the engineer shall,
(a) determine the area requiring drainage;
(b) determine whether the petition complies with section 4 for the area requiring drainage; and
(c) where the engineer is of opinion that the petition fails to so comply, establish the requirements for a petition to comply with section 4. R.S.O. 1990, c. D.17, s. 9 (2).
Idem
(3) Where the engineer is of opinion that the petition complies with section 4, the engineer shall proceed to prepare a report or a preliminary report, as the case may be. R.S.O. 1990, c. D.17, s. 9 (3).
Report of engineer
(4) Where the engineer is of opinion that the petition does not comply with section 4, the engineer shall so report to the council of the initiating municipality stating wherein the petition is deficient, the amount of the engineer’s fees and by whom they shall be paid, and the council shall forthwith send a copy of such opinion to each petitioner. R.S.O. 1990, c. D.17, s. 9 (4).
Fees to form part of costs
(5) Where, within sixty days of the engineer’s reporting to council under subsection (4), a petition that complies with the requirements of section 4 is filed with the clerk of the council,
(a) the council shall instruct the engineer to prepare a report, or a preliminary report, as the case may be; and
(b) the fees mentioned in subsection (4) shall form part of the cost of the drainage works. R.S.O. 1990, c. D.17, s. 9 (5).
Preliminary report
10. (1) Where the council of the initiating municipality deems it expedient, it may, or if it has received notice under section 6 that an environmental appraisal is required, it shall instruct the engineer to prepare a preliminary report containing a sketched plan of the drainage works and an estimate of the cost thereof in so far as it is practicable to do so, and which shall include the environmental appraisal, if any, and the benefit cost statement, if any, and the engineer shall forthwith prepare and file such a preliminary report with the council. R.S.O. 1990, c. D.17, s. 10 (1).
Consideration of report
(2) Upon the filing of the preliminary report, the council of the initiating municipality shall cause the clerk to send a copy of the preliminary report and a notice of the date of the council meeting at which the preliminary report will be considered, to,
(a) every owner of land within the area requiring drainage as determined by the engineer or described in the petition, as the case may be;
(b) any public utility or road authority that may be affected by the drainage works;
(c) any local municipality and conservation authority entitled to notice under section 5 or, if no authority is entitled to notice, to the Minister of Natural Resources; and
(d) the Minister. R.S.O. 1990, c. D.17, s. 10 (2).
Withdrawal from and additions to petition
(3) At the meeting referred to in subsection (2), the council shall consider the preliminary report and shall give to any person who signed the petition an opportunity to withdraw from it by putting a withdrawal in writing, signing it and filing it with the clerk, and to any person present who owns land in the area requiring drainage and has not signed the petition an opportunity to do so. R.S.O. 1990, c. D.17, s. 10 (3).
Cost of petition and preliminary report
(4) If at the end of the meeting the petition does not contain a sufficient number of names to comply with section 4, the original petitioners are chargeable in equal shares with and liable to the municipality for the expenses incurred by the municipality in connection with the petition and preliminary report, excluding the amount of any grants and the costs of any environmental appraisal or benefit cost statement, and the sum with which each of such petitioners is chargeable shall be entered upon the collector’s roll for the municipality against the lands of the person liable and shall be collected in the same manner as real property taxes. R.S.O. 1990, c. D.17, s. 10 (4).
Instruction to engineer
(5) If at the end of the meeting, the petition contains a sufficient number of names to comply with section 4, the council may instruct the engineer to proceed with the preparation of a report. R.S.O. 1990, c. D.17, s. 10 (5).
Appeal to Tribunal
(6) Where the council of the initiating municipality fails to instruct the engineer to proceed with the preparation of a report, any petitioner may appeal to the Tribunal or, where lands used for agricultural purposes are included in the area to be drained, the Minister may refer the matter to the Tribunal and the Tribunal may direct the council to take such action as the council is authorized to take under this Act and as the Tribunal considers proper. R.S.O. 1990, c. D.17, s. 10 (6); 2006, c. 19, Sched. A, s. 6 (3).
Idem
(7) Where any party mentioned in clause (2) (a), (b) or (c) is dissatisfied with the environmental appraisal, an appeal lies to the Tribunal. R.S.O. 1990, c. D.17, s. 10 (7); 2006, c. 19, Sched. A, s. 6 (1).
Referral to Tribunal
(8) Where,
(a) lands used for agricultural purposes are included in the area to be drained, the Minister; or
(b) a conservation authority or regional office of the Ministry of Natural Resources reports to the Minister of Natural Resources that the environmental appraisal is unsatisfactory, the Minister of Natural Resources,
may refer the environmental appraisal to the Tribunal. R.S.O. 1990, c. D.17, s. 10 (8); 2006, c. 19, Sched. A, s. 6 (1).
Powers of Tribunal
(9) An appeal under subsection (7) or a reference under subsection (8) shall be made within forty days after the meeting referred to in subsection (2), and the Tribunal may confirm the environmental appraisal or direct that it be reconsidered in such respects as the Tribunal considers proper. R.S.O. 1990, c. D.17, s. 10 (9); 2006, c. 19, Sched. A, s. 6 (1).
Duties of engineer
11. The engineer shall, to the best of the engineer’s skill, knowledge, judgment and ability, honestly and faithfully, and without fear of, favour to or prejudice against any person, perform the duty assigned to the engineer in connection with any drainage works and make a true report thereon. R.S.O. 1990, c. D.17, s. 11.
Power to enter on lands
12. (1) The engineer or any of the engineer’s assistants when engaged in the performance of their duties during or after the examination of the locality may enter, measure along, ascertain the bearings of any line, plant the stakes that they consider necessary for the performance of the work and take levels on the land of any person. R.S.O. 1990, c. D.17, s. 12 (1).
Offence, obstruction of engineer
(2) Every person who wilfully interferes with or obstructs the engineer or any of the engineer’s assistants in the exercise of the powers conferred by this section is guilty of an offence and on conviction is liable to a fine of not more than $1,000. R.S.O. 1990, c. D.17, s. 12 (2).
Duties re survey
13. (1) The engineer in making a survey shall establish sufficient bench marks or permanent levels by which a drainage works may be governed, and shall in the report record the description, location and elevation of every bench mark or permanent level. R.S.O. 1990, c. D.17, s. 13 (1).
Offence, interference with bench marks
(2) Every person who interferes with, removes or destroys any bench mark or permanent level established under this section is guilty of an offence and on conviction is liable to a fine of not more than $1,000. R.S.O. 1990, c. D.17, s. 13 (2).
Providing capacity for covered drainage works
14. (1) Subject to subsection (2), the construction of a drainage works by means of the improvement of a natural watercourse shall not include a covered drainage works, unless the part of the drainage works in which the covered drainage works is included provides capacity for all the surface water from the lands and roads draining naturally towards and into it and for all the waters from all the lands and roads assessed for the drainage works. R.S.O. 1990, c. D.17, s. 14 (1).
Covered drainage works may be employed
(2) A covered drainage works may be employed in conjunction with an open drain provided that the total capacity of the system is sufficient for the purposes of subsection (1). R.S.O. 1990, c. D.17, s. 14 (2).
Sufficient outlet
15. Subject to section 32, every drainage works constructed under this Act shall be continued to a sufficient outlet. R.S.O. 1990, c. D.17, s. 15.
Report re disposal of material taken from drainage works
16. The engineer in the report shall determine in what manner the material taken from any drainage works in the construction, improvement, repair or maintenance thereof shall be disposed of. R.S.O. 1990, c. D.17, s. 16.
Bridges and culverts on roads
17. The engineer in the report shall provide for the construction, enlargement or other improvement of any bridges or culverts throughout the course of the drainage works rendered necessary by the drainage works crossing any public road or part thereof. R.S.O. 1990, c. D.17, s. 17.
Construction of bridges, etc.
18. Subject to section 33, the engineer in the report shall provide for the construction or the replacement, enlargement or other improvement of bridges, culverts, pumping stations and water gates rendered necessary by the drainage works including the cost of the construction or the replacement, enlargement or other improvement of the bridges, pumping stations, water gates and culverts, in the assessment for the construction, improvement, maintenance or repair of the drainage works, and they shall, for the purposes of maintenance or repair, be deemed part of the drainage works. R.S.O. 1990, c. D.17, s. 18.
Engineer may recommend abandonment of drain
19. The engineer in the report may recommend the abandonment of any drain or part thereof that is no longer useful or that is being supplanted by a new drainage works. R.S.O. 1990, c. D.17, s. 19.
Continuing drainage works beyond limits of municipality
20. (1) Where it is considered necessary to continue a drainage works beyond the limits of the initiating municipality, the engineer employed by the council of the municipality may continue the drainage works on or along or across any road allowance or other boundary between any two or more municipalities, and from any such road allowance or other boundary into or through any municipality until the engineer reaches a sufficient outlet. R.S.O. 1990, c. D.17, s. 20 (1).
Where drainage works not deemed outside initiating municipality
(2) A drainage works shall not be deemed to be continued into a municipality other than the initiating municipality merely by reason of such drainage works or some part thereof being constructed on a road allowance forming the boundary line between two or more municipalities. R.S.O. 1990, c. D.17, s. 20 (2).
Engineer to distinguish assessments
21. The engineer in the report shall assess for benefit, outlet liability and injuring liability, and shall insert in an assessment schedule, in separate columns, the sums assessed for each opposite each parcel of land and road liable therefor. R.S.O. 1990, c. D.17, s. 21.
Assessment for benefit
22. Lands, roads, buildings, utilities or other structures that are increased in value or are more easily maintained as a result of the construction, improvement, maintenance or repair of a drainage works may be assessed for benefit. R.S.O. 1990, c. D.17, s. 22.
Assessment for liability
Outlet liability
23. (1) Lands and roads that use a drainage works as an outlet, or for which, when the drainage works is constructed or improved, an improved outlet is provided either directly or indirectly through the medium of any other drainage works or of a swale, ravine, creek or watercourse, may be assessed for outlet liability. R.S.O. 1990, c. D.17, s. 23 (1).
Injuring liability
(2) If, from any land or road, water is artificially caused by any means to flow upon and injure any other land or road, the land or road from which the water is caused to flow may be assessed for injuring liability with respect to a drainage works to relieve the injury so caused to such other land or road. R.S.O. 1990, c. D.17, s. 23 (2).
Basis of assessment
(3) The assessment for outlet liability and injuring liability provided for in subsections (1) and (2) shall be based upon the volume and rate of flow of the water artificially caused to flow upon the injured land or road or into the drainage works from the lands and roads liable for such assessments. R.S.O. 1990, c. D.17, s. 23 (3).
Certain owners not to count for or against petition
(4) The owners of the lands and roads made liable to assessment only under subsection (1) or (2) shall neither count for nor against the petition required by section 4 unless within the area therein described. R.S.O. 1990, c. D.17, s. 23 (4).
Assessment for special benefit
24. The engineer may assess for special benefit any lands for which special benefits have been provided by the drainage works. R.S.O. 1990, c. D.17, s. 24.
Engineer may assess a block, etc.
25. (1) The council of the local municipality may direct the engineer to assess as a block, a built-up area designated by the council, and the sum assessed therefor may be levied against all the rateable properties in the designated area proportionately on the basis of the assessed value of the land and buildings. R.S.O. 1990, c. D.17, s. 25 (1).
Assessment to be charged against public roads
(2) Where the engineer makes a block assessment under subsection (1), the engineer shall designate the proportion of the assessment to be charged against the public roads in the designated area. R.S.O. 1990, c. D.17, s. 25 (2).
Increased cost, how borne
26. In addition to all other sums lawfully assessed against the property of a public utility or road authority under this Act, and despite the fact that the public utility or road authority is not otherwise assessable under this Act, the public utility or road authority shall be assessed for and shall pay all the increase of cost of such drainage works caused by the existence of the works of the public utility or road authority. R.S.O. 1990, c. D.17, s. 26.
Assessment where drainage works continued beyond limits of municipality
27. Where a drainage works is continued into or through a municipality other than the initiating municipality under section 20, the engineer may assess, regardless of municipal boundaries, all lands and roads that, in the engineer’s opinion, should be assessed for benefit, outlet liability or injuring liability, with such proportion of the cost of the drainage works as appears just, and in the report thereon the engineer shall estimate separately the cost of the drainage works within each municipality and upon the road allowances or other boundaries. R.S.O. 1990, c. D.17, s. 27.
Assessing lands in neighbouring municipality
28. Where any lands or roads in or under the jurisdiction of a local municipality, other than the local municipalities into or through which the drainage works passes, are, in the opinion of the engineer of the initiating or other municipality doing the work or part thereof, benefited by the drainage works or provided with an improved outlet or relieved from injuring liability, the engineer may assess the cost of the construction, improvement, maintenance or repair of the drainage works in the same manner as is provided in section 27. R.S.O. 1990, c. D.17, s. 28.
Allowances for right of way, etc.
29. The engineer in the report shall estimate and allow in money to the owner of any land that it is necessary to use,
(a) for the construction or improvement of a drainage works;
(b) for the disposal of material removed from drainage works;
(c) as a site for a pumping station to be used in connection with a drainage works; or
(d) as a means of access to any such pumping station, if, in the opinion of the engineer, such right of way is sufficient for the purposes of the drainage works,
the value of any such land or the damages, if any, thereto, and shall include such sums in the estimates of the cost of the construction, improvement, repair or maintenance of the drainage works. R.S.O. 1990, c. D.17, s. 29.
Amount for damage to ornamental trees, etc.
30. The engineer shall determine the amount to be paid to persons entitled thereto for damage, if any, to ornamental trees, lawns, fences, lands and crops occasioned by the disposal of material removed from a drainage works and shall include such sums in the estimates of the cost of the construction, improvement, repair or maintenance of the drainage works. R.S.O. 1990, c. D.17, s. 30.
Allowance for existing drains
31. Where an existing drain that was not constructed on requisition or petition under this Act or any predecessor of this Act is incorporated in whole or in part in a drainage works, the engineer in the report shall estimate and allow in money to the owner of such drain or part the value to the drainage works of such drain or part and shall include such sum in the estimates of the cost of the construction, improvement, repair or maintenance of the drainage works. R.S.O. 1990, c. D.17, s. 31.
Allowance for damage due to insufficient outlet
32. Where, in the opinion of the engineer, the cost of continuing a drainage works to a sufficient outlet or the cost of constructing or improving a drainage works with sufficient capacity to carry off the water will exceed the amount of injury likely to be caused to low-lying lands along the course of or below the termination of the drainage works, instead of continuing the works to such an outlet, or making it of such capacity, the engineer may include in the estimate of cost a sufficient sum to compensate the owners of such low-lying lands for any injuries they may sustain from the drainage works, and in the report the engineer shall determine the amount to be paid to the owners of such low-lying lands in respect of such injuries. R.S.O. 1990, c. D.17, s. 32.
Allowance for loss of access
33. Where the engineer thinks it expedient to make an allowance for loss of access to an owner instead of providing for the construction or the replacement, enlargement or other improvement of a bridge, the engineer shall in the report provide for payment to the owner of such amount as appears just by way of allowance for loss of access and shall include such sums in the estimates of the cost of the construction, improvement, repair or maintenance of the drainage works. R.S.O. 1990, c. D.17, s. 33.
Prior assessments to be taken into consideration
34. In fixing the sum to be assessed upon any land or road, the engineer may take into consideration any prior assessment or allowance on the same land or road for the construction, improvement, maintenance or repair of a drainage works and make such adjustment therefor as appears just, and in the report the engineer shall state the adjustment so made. R.S.O. 1990, c. D.17, s. 34.
Assessment may be shown in money
35. The assessment upon any land or road for a drainage works shall be shown by the engineer placing in a schedule to the report sums of money opposite the land or road, and, where the engineer considers it advisable, the fractional part of the whole cost to be borne by the land or road. R.S.O. 1990, c. D.17, s. 35.
Assessment of affected land
36. The engineer, in assessing the lands and roads requiring drainage or otherwise liable for assessment under this Act, shall show in the report the approximate number of hectares affected by the drainage works in each parcel of land assessed for the drainage works. R.S.O. 1990, c. D.17, s. 36.
Engineer to assess separately
37. The engineer in the report shall list separately the lands in each municipality that are assessed for a drainage works and shall indicate the assessment for the cost of lateral drains and the assessments of lands that are not agricultural lands. R.S.O. 1990, c. D.17, s. 37.
Variation in assessments for maintenance and repair
38. Where the engineer considers it equitable that the cost of the maintenance and repair of a drainage works be assessed upon a basis different from that upon which the cost of its construction or improvement is assessed, the engineer shall determine and report the basis upon which the cost of maintenance and repair of the drainage works or of any part or parts thereof shall be assessed. R.S.O. 1990, c. D.17, s. 38.
Time for filing report
39. (1) The engineer shall file the report with the clerk of the initiating municipality as soon as it is completed or in any event within six months after the appointment of the engineer or within such further time as may be extended before or after the expiry of such six-month period by the council of the municipality by resolution. R.S.O. 1990, c. D.17, s. 39 (1).
Engineer may forfeit compensation
(2) Where, after thirty days notice by council, the engineer neglects to make a report within the time limited by or extended under this section, the engineer shall forfeit all claims for compensation for the work done upon the drainage works, and the council of the local municipality may appoint another engineer. R.S.O. 1990, c. D.17, s. 39 (2).
By-law not invalid by reason report not filed
(3) A by-law passed by the council of any local municipality for the construction of a drainage works under this Act shall not be quashed by reason only that the report of the engineer was not filed within the time limited by or extended under this section. R.S.O. 1990, c. D.17, s. 39 (3).
Engineer’s finding, drainage works not required, etc.
40. Where the engineer finds that a drainage works is not required or is impractical, or cannot be constructed under this Act, the engineer shall forthwith file with the clerk of the initiating municipality a report to that effect, stating the reasons therefor, the amount of the engineer’s fees and other charges and by whom they shall be paid, and the clerk shall forthwith send a notice of the filing of such report, by prepaid mail, to all persons who signed the petition or requisition, as the case may be, and the matter shall not be further proceeded with unless the decision of the engineer is reversed on appeal. R.S.O. 1990, c. D.17, s. 40.
Notice of drainage works
41. (1) Upon the filing of the engineer’s report, the council of the initiating municipality, if it intends to proceed with the drainage works, shall, within thirty days of the filing of the report, cause the clerk of the initiating municipality to send a copy of the report and a notice by prepaid mail stating,
(a) the date of the filing of the report;
(b) the name or other designation of the drainage works; and
(c) the date of the council meeting at which the report will be considered,
to,
(d) the owners, in the initiating municipality, as shown by the last revised assessment roll to be the owners of lands and roads assessed for the drainage works or for which compensation or other allowances have been provided in the report;
(e) the clerk of every other local municipality in which any land or road that is assessed for the drainage works or for which compensation or other allowances have been provided in the report is situate;
(f) the secretary-treasurer of each conservation authority that has jurisdiction over any land affected by the report;
(g) any railway company, public utility or road authority affected by the report, other than by way of assessment;
(h) the Minister of Natural Resources where land under his or her jurisdiction may be affected by the report; and
(i) the Director. R.S.O. 1990, c. D.17, s. 41 (1).
Clerk to notify persons assessed
(2) The clerk of every other local municipality in which any land or road that is assessed for the drainage works or for which compensation or other allowances have been provided in the report is situate shall send within thirty days of the sending of the last notice under subsection (1) a copy of the report and notice by prepaid mail to the owners, as shown by the last revised assessment roll to be the owners of the lands and roads in such municipality assessed for the drainage works, or for which compensation or other allowance has been provided in the report stating,
(a) the date of the filing of the report;
(b) the name or other designation of the drainage works; and
(c) the date of the council meeting of the initiating municipality at which the report will be considered. R.S.O. 1990, c. D.17, s. 41 (2).
Copy of report not required
(3) Despite subsections (1) and (2), where a block assessment is made, the notice to the owners of the lands so assessed need not be accompanied by a copy of the report. R.S.O. 1990, c. D.17, s. 41 (3).
Same
(3.1) Despite subsections (1) and (2), the council of a local municipality is not required to send a copy of the report to owners of lands and roads assessed for a sum of less than $100. 1998, c. 18, Sched. A, s. 1 (1).
Council meeting for consideration of report
(4) The date of the council meeting at which the report will be considered shall not be less than ten days after the last notice has been mailed under subsections (1) and (2). R.S.O. 1990, c. D.17, s. 41 (4).
By-law not to be quashed
(5) A by-law passed by the council of any local municipality in connection with the construction of a drainage works under this Act shall not be quashed by reason only that any notices required under this section were not sent within the specified time limits. R.S.O. 1990, c. D.17, s. 41 (5).
Consideration of report
42. The council of the initiating municipality at the meeting mentioned in section 41 shall consider the report, and, where the drainage works is requested on petition, shall give an opportunity to any person who has signed the petition to withdraw from it by putting a withdrawal in writing, signing it and filing it with the clerk, and shall also give those present owning lands within the area requiring drainage who have not signed the petition an opportunity to do so, and should any of the lands or roads owned by the municipality within the area requiring drainage as described in the petition be assessed, the council may by resolution authorize the head of the municipality to sign the petition for the municipality, and such signature counts as that of one person in favour of the petition. R.S.O. 1990, c. D.17, s. 42.
Liability of original petitioners
43. If, after striking out the names of the persons withdrawing, the names remaining on the petition, including the names, if any, added as provided by section 42 do not comply with section 4, the original petitioners on their respective assessments in the report are chargeable proportionately with and liable to the municipality for the expenses incurred by the municipality in connection with the petition and report and the sum with which each of such petitioners is chargeable shall be entered upon the collector’s roll for the municipality against the lands of the person liable, and shall be collected in the same manner as real property taxes. R.S.O. 1990, c. D.17, s. 43.
Sufficiency of petition
44. If, at the end of such council meeting, the petition contains a sufficient number of names to comply with section 4, the council may proceed to adopt the report, and, subject to section 59, no person having signed the petition shall, after the adoption of the report, be permitted to withdraw. R.S.O. 1990, c. D.17, s. 44.
Adoption of report
45. (1) A report may be adopted by by-law in the form prescribed by the regulations and, when such by-law is given two readings by council, the report shall be deemed to be adopted and the by-law shall be known as a provisional by-law. R.S.O. 1990, c. D.17, s. 45 (1).
Appeal or referral to Tribunal
(2) Where a report is not adopted by council, any petitioner may appeal to the Tribunal or, where lands used for agricultural purposes are included in the area to be drained, the Minister may refer the matter to the Tribunal. R.S.O. 1990, c. D.17, s. 45 (2); 2006, c. 19, Sched. A, s. 6 (1).
Notice of court of revision to be sent to local municipalities and to owners
46. (1) The council of the initiating municipality shall, within five days after the adoption of the report, send a copy of the provisional by-law, exclusive of the engineer’s report, and a notice of the time and place of the first sitting of the court of revision by prepaid mail to every other local municipality in which any land or road is assessed for the drainage works or for which allowance or compensation has been provided for in the report. R.S.O. 1990, c. D.17, s. 46 (1).
Idem
(2) The council of the initiating municipality and of every local municipality to whom a copy of the provisional by-law is sent under subsection (1) shall, within thirty days after the adoption of the report, send a copy of the provisional by-law, exclusive of the engineer’s report, and a notice of the time and place of the sitting of the court of revision by prepaid mail to each person or body entitled to notice under section 41 and the notice shall inform each owner that the owner may appeal the owner’s assessment to the court of revision by a notice given to the clerk of the initiating municipality not later than ten days prior to the first sitting of the court of revision. R.S.O. 1990, c. D.17, s. 46 (2).
Sittings of court
(3) The first sitting of the court of revision shall be held on a day not earlier than twenty nor later than thirty days from the date of completing the mailing of the copies of the provisional by-law under subsection (2). R.S.O. 1990, c. D.17, s. 46 (3).
Appeal from report to referee
47. (1) Any owner of land or public utility affected by a drainage works, if dissatisfied with the report of the engineer on the grounds that it does not comply with the requirements of this Act, or that the engineer has reported that the drainage works cannot be constructed under section 4, may appeal to the referee and in every case a written notice of appeal shall be served upon the council of the initiating municipality within forty days after the mailing of the notices under section 40 or subsection 46 (2), as the case may be. R.S.O. 1990, c. D.17, s. 47 (1).
Notice to court clerk
(2) Upon receipt of a notice of appeal under subsection (1), the clerk of the municipality shall forthwith record the notice and send a copy of the notice to the clerk of the court of the referee. R.S.O. 1990, c. D.17, s. 47 (2).
Appeal to Tribunal
48. (1) Any owner of land or any public utility affected by a drainage works, if dissatisfied with the report of the engineer on the grounds that,
(a) the benefits to be derived from the drainage works are not commensurate with the estimated cost thereof;
(b) the drainage works should be modified on grounds to be stated;
(c) the compensation or allowances provided by the engineer are inadequate or excessive;
(d) the engineer has reported that the drainage works is not required, or is impractical, or cannot be constructed under section 3,
may appeal to the Tribunal, and in every case a written notice of appeal shall be served within forty days after the mailing of the notice under section 40 or subsection 46 (2), as the case may be. R.S.O. 1990, c. D.17, s. 48 (1); 2006, c. 19, Sched. A, s. 6 (1).
Appeal by Director
(2) Where lands used for agricultural purposes may be affected by the drainage works, the Director may appeal to the Tribunal on any of the grounds and in the manner mentioned in subsection (1). R.S.O. 1990, c. D.17, s. 48 (2); 2006, c. 19, Sched. A, s. 6 (1).
Appeal by conservation authority
49. Where the proposed drainage works is to be undertaken within a watershed in which a conservation authority has jurisdiction, the authority may appeal from the report of the engineer to the Tribunal on the ground that the drainage works will injuriously affect a scheme undertaken by the authority under the Conservation Authorities Act, and in every case a written notice of appeal shall be served within forty days after the mailing of the notices under subsection 46 (2). R.S.O. 1990, c. D.17, s. 49; 2006, c. 19, Sched. A, s. 6 (1).
Appeal by municipality
50. (1) The council of any local municipality to which a copy of a provisional by-law was sent under subsection 46 (1) may, within forty days after the copy of the provisional by-law was sent to the clerk, appeal to the Tribunal from the report by serving the clerk of the initiating municipality and the clerk of every other municipality assessed by the engineer with a written notice of appeal setting forth the reasons for such appeal. R.S.O. 1990, c. D.17, s. 50 (1); 2006, c. 19, Sched. A, s. 6 (1).
Reasons for appeal
(2) The reasons for appeal may be the following, or any of them,
(a) that the proposed drainage works as it affects the appealing municipality should be abandoned or modified, on grounds to be stated;
(b) that the course of the drainage works or any part thereof should be altered;
(c) that the drainage works does not provide a sufficient outlet;
(d) that the drainage works should be carried to an outlet in the initiating municipality or elsewhere;
(e) that a petition has been received by the council of the appealing municipality, as provided by section 4, for the enlargement by the appealing municipality of any part of a drainage works lying within its limits, and thence to an outlet, and that the council is of opinion that such enlargement is desirable to afford drainage facilities for the area described in the petition;
(f) the work is unnecessary; or
(g) that the assessment against lands and roads within the limits of the appealing municipality and roads under its jurisdiction is illegal, unjust or excessive. R.S.O. 1990, c. D.17, s. 50 (2).
Powers of Tribunal
51. (1) On any appeal or reference to the Tribunal under this Act, the Tribunal shall hear and determine the matter and, where not so provided, may make such order and direct such things to be done as are authorized by this Act or as it considers proper to carry out the purposes of this Act. R.S.O. 1990, c. D.17, s. 51 (1); 2006, c. 19, Sched. A, s. 6 (4).
Parties
(2) The parties to an appeal or reference to the Tribunal under this Act shall be the person making the appeal or reference and such other persons as the Tribunal may specify. R.S.O. 1990, c. D.17, s. 51 (2); 2006, c. 19, Sched. A, s. 6 (4).
Appeals
52. (1) Any owner of land assessed for the drainage works who complains that any land or road has been assessed too high or too low or that any land or road that should have been assessed has not been assessed, or that due consideration has not been given as to type of use of land, may appeal to the court of revision by giving notice in writing to the clerk of the initiating municipality setting out the grounds of the appeal, and the appeal shall be heard by the court of revision. R.S.O. 1990, c. D.17, s. 52 (1); 2006, c. 21, Sched. C, s. 107.
Notices of appeal
(2) Every notice of appeal shall be given at least ten days before the first sitting of the court, but the court may, though notice of appeal has not been given, by resolution passed at its first sitting, allow an appeal to be heard on such conditions as to giving notice to all persons interested or otherwise as appear just. R.S.O. 1990, c. D.17, s. 52 (2).
Adjournment of court or Tribunal
53. When the ground of appeal is that lands or roads are assessed too high and the evidence adduced satisfies the court of revision or Tribunal that the assessments on such lands or roads should be reduced and there is no evidence to indicate that the amount of such reduction should be levied against lands or roads whose owners are parties to appeals then pending before the court of revision or Tribunal, the court or Tribunal shall adjourn the hearing of the appeal for a time sufficient to enable the clerk to notify by prepaid mail such persons as the appellant may specify who are shown by the last revised assessment roll to be owners of land affected of the date to which the hearing is adjourned, and the clerk shall so notify all such persons, and at such adjourned hearing the court or Tribunal shall dispose of the matter of appeal and, where appropriate, redistribute the assessments in such manner as appears just. R.S.O. 1990, c. D.17, s. 53; 2006, c. 19, Sched. A, s. 6 (5).
Appeal to Tribunal
54. (1) Any party to an appeal before the court of revision may appeal to the Tribunal by giving notice addressed to the clerk of the Tribunal, given to the clerk of the initiating municipality, from the decision of the court of revision or from its omission, neglect or refusal to hear or decide an appeal within twenty-one days of the pronouncement of the decision of the court of revision or of any matter evidencing such omission, neglect or refusal. R.S.O. 1990, c. D.17, s. 54 (1); 2006, c. 19, Sched. A, s. 6 (1).
Notice
(2) The clerk of the Tribunal shall give ten days notice to an appellant of the time and place of the hearing of the appeal by the Tribunal. R.S.O. 1990, c. D.17, s. 54 (2); 2006, c. 19, Sched. A, s. 6 (1).
Procedure
(3) Every appeal shall be heard by the Tribunal by way of a new hearing and shall be disposed of by the Tribunal in such manner as it considers proper, and its decision is final. R.S.O. 1990, c. D.17, s. 54 (3); 2006, c. 19, Sched. A, s. 6 (6).
Evidence by engineer
55. In any appeal to the court of revision or to the Tribunal in which the engineer is called upon to give evidence as to how an assessment was determined, the engineer shall give evidence before the appellant’s case is presented. R.S.O. 1990, c. D.17, s. 55; 2006, c. 19, Sched. A, s. 6 (1).
Clerk to alter assessments
56. Any change in an assessment made by the court of revision or by the Tribunal shall be given effect to by the clerk of the local municipality altering the assessments and other parts of the schedule to comply therewith and sending notice thereof to the owners affected, and the provisional by-law shall, before the passing thereof, be amended to carry out any changes so made by the court of revision or by the Tribunal. R.S.O. 1990, c. D.17, s. 56; 2006, c. 19, Sched. A, s. 6 (1).
Referral back to engineer
57. The council of the initiating municipality, at any time before passing the by-law, if it appears that there are or may be errors in the report of the engineer or that for any other reason the report should be reconsidered, may refer the report back to the engineer for reconsideration, and the engineer shall thereupon reconsider the report and shall further report to the council, which report has the same effect and shall be dealt with in the same manner and the proceedings thereon shall be the same as upon the original report. R.S.O. 1990, c. D.17, s. 57.
By-law may be passed
58. (1) Where the council of an initiating municipality has adopted a report for the construction of a drainage works after the time for appealing has expired and there are no appeals or after all appeals have been decided, the council may pass a provisional by-law thereby authorizing the construction of the drainage works, and work may be commenced ten days after the by-law is passed if no notice of intention to make application to quash the by-law has been filed with the clerk of the council. R.S.O. 1990, c. D.17, s. 58 (1).
Quashing of by-law
(2) If no notice of intention to make application to quash a by-law is filed with the clerk of the council within ten days after the passing of the by-law or, where a notice of intention has been given, if an application to quash is not made to the referee within three months after the passing of the by-law, the by-law, or so much thereof as is not the subject of or is not quashed upon any such application, is valid and binding according to its terms, so far as it prescribes or directs anything within the proper competence of the council. R.S.O. 1990, c. D.17, s. 58 (2).
Repeal of by-law
(3) A by-law may be repealed at any time before the work is commenced and before any assessment has been levied against the land assessed, and in such case the council of the initiating municipality shall pay all expenses in connection therewith out of the general funds of the municipality. R.S.O. 1990, c. D.17, s. 58 (3).
Where error in report
(4) If, at any time after the by-law is passed and before any assessments are levied, a gross error in the report is found, the council of the initiating municipality may on notice to all persons assessed apply to the Tribunal to correct the error. R.S.O. 1990, c. D.17, s. 58 (4); 2006, c. 19, Sched. A, s. 6 (1).
Appeal to Tribunal
(5) Where the council does not proceed with reasonable dispatch with the construction of the work after passage of the by-law, a requisitioner or a petitioner may appeal to the Tribunal or, where lands used for agricultural purposes are included in the area to be drained, the Minister may refer the matter to the Tribunal, and the Tribunal may direct the council to take such action as the council is authorized to take under this Act and as the Tribunal considers proper. R.S.O. 1990, c. D.17, s. 58 (5); 2006, c. 19, Sched. A, s. 6 (1).
Meeting to consider contract price
59. (1) Where the contract price exceeds 133 per cent of the engineer’s estimate of the contract price, the council of the initiating municipality shall call a meeting in the manner prescribed by section 41, and sections 42 and 43 apply with necessary modifications. R.S.O. 1990, c. D.17, s. 59 (1).
Council may proceed with construction
(2) If at the close of the meeting the petition contains a sufficient number of names to comply with section 4, the council may proceed with the construction of the drainage works. R.S.O. 1990, c. D.17, s. 59 (2).
Municipalities required to raise cost
60. The council of each local municipality to which a copy of the report is required to be sent under subsection 41 (1) shall raise and pay over to the treasurer of the initiating municipality its proportion of the cost of the construction of the drainage works within sixty days after the drainage works has been certified complete by the engineer or a drainage superintendent. R.S.O. 1990, c. D.17, s. 60; 1998, c. 18, Sched. A, s. 1 (2).
Imposition of special assessment
61. (1) The council of each local municipality that is required to raise the whole or any part of the cost of the drainage works shall by by-law impose upon the land assessed for the drainage works the assessment with which it is chargeable, and the amount so imposed is payable in such instalments as the council may prescribe. R.S.O. 1990, c. D.17, s. 61 (1).
Commutation of special assessment
(2) The council of any local municipality may provide that persons whose lands are assessed may commute for a payment in cash the assessments imposed thereon and may prescribe the terms and conditions thereof. R.S.O. 1990, c. D.17, s. 61 (2).
Assessments of $50 or less
(3) Where the assessment against any parcel of land is $50 or less, the council of the local municipality may provide that the assessment shall be paid out of the general funds of the municipality or that the assessment shall be paid in the first year in which the assessment is imposed upon the land assessed. R.S.O. 1990, c. D.17, s. 61 (3).
Priority lien
(4) The assessments and rates imposed under this Act shall have priority lien status as described in section 1 of the Municipal Act, 2001 or section 3 of the City of Toronto Act, 2006, as the case may be. 2002, c. 17, Sched. F, Table; 2006, c. 32, Sched. C, s. 14.
Lands exempt from taxation to be specially assessed
(5) Despite any general or special Act, land exempt from taxation is for all purposes, except petitioning for or against undertaking a drainage works, subject to the provisions of this Act and shall be assessed, and the assessments so imposed that fall due while such land remains exempt from taxation shall be paid by the municipality that imposed the assessments, provided that such assessments imposed upon land on which a church or place of worship is erected and that is used in connection therewith, land of a university, college or seminary of learning, whether vested in a trustee or otherwise, and land of a board of an elementary or secondary school as defined in the Education Act and land owned by an upper-tier municipality, shall be paid by the owners of the land. R.S.O. 1990, c. D.17, s. 61 (5); 2002, c. 17, Sched. F, Table.
Amendment of by-law
62. (1) Any by-law for the assessment upon the lands and roads liable to contribute for any drainage works that has been acted upon by the completion of the drainage works in whole or in part shall, where more than sufficient funds or where insufficient funds have been provided for the completion of or proper contribution towards the drainage works or for the redemption of the debentures authorized to be issued thereunder as they become payable, be amended, and, if lands and roads in any other municipality are assessed for the drainage works, the surplus or deficiency of money shall be divided proportionately among the contributing municipalities, and every such surplus or deficiency shall be applied by the council of the municipality proportionately according to the assessment in payment of the rates imposed by it for the drainage works. R.S.O. 1990, c. D.17, s. 62 (1).
When lands and roads in another municipality assessable
(2) Where a by-law provides insufficient funds and lands and roads in another municipality are assessed for the drainage works, the council of the initiating municipality shall appoint an engineer to make an examination of the drainage works and report upon it with an estimate of the cost of completion for which sufficient funds have not been provided under the original by-law, and shall notify the heads of the other local municipalities as in the case of the original report, and the council of any municipality so notified has a right of appeal to the Tribunal in the manner provided by section 50 on the grounds of the improper expending or unlawful or other application of the drainage money already raised and is subject to the same duty, as to raising and paying over its share of the money to be raised, as in the case of the original by-law. R.S.O. 1990, c. D.17, s. 62 (2); 2006, c. 19, Sched. A, s. 6 (1).
Responsibility of owner for payment
(3) Where any allowance or compensation has been determined for an owner under sections 29 to 33, the council may, where the amount so determined is less than the total amount owing from that owner, deduct from that total the amount so determined and the owner shall be responsible for paying the balance in the manner prescribed by the by-law. R.S.O. 1990, c. D.17, s. 62 (3).
Payment of balance
(4) Where any allowance or compensation mentioned in subsection (3) exceeds the total amount owing by the owner, the municipality shall pay the balance to the owner. R.S.O. 1990, c. D.17, s. 62 (4).
Powers of contractor
63. (1) The contractor and the contractor’s assistants when engaged in the construction, maintenance, improvement or repair of a drainage works may, with their equipment, enter upon whatever lands are necessary to complete the work within the working space designated in the engineer’s report. R.S.O. 1990, c. D.17, s. 63 (1).
Penalty for obstruction
(2) Every person who wilfully interferes with or obstructs the contractor or any of the contractor’s assistants in the exercise of the powers conferred by subsection (1) is guilty of an offence and on conviction is liable to a fine of not more than $1,000. R.S.O. 1990, c. D.17, s. 63 (2).
Appeal by owner of land
64. Any owner of land dissatisfied with the quality of the construction of a drainage works constructed under this Act may, at any time during construction or up to one year from the date of completion of the drainage works as certified by the engineer or a drainage superintendent of the drainage works, appeal to the Tribunal on grounds to be stated. R.S.O. 1990, c. D.17, s. 64; 1998, c. 18, Sched. A, s. 1 (3); 2006, c. 19, Sched. A, s. 6 (1).
Subsequent subdivision of land
65. (1) Subject to subsection (6), where a parcel of land has been assessed by an engineer and, after the final revision of the assessment, the parcel is divided by the change in ownership of any part, the clerk of the local municipality in which the parcel is situate shall instruct an engineer in writing to apportion the assessment charged against the parcel among the parts into which it is divided. R.S.O. 1990, c. D.17, s. 65 (1).
Notice to affected owners
(2) The clerk of the local municipality shall forthwith send a copy of the instructions by prepaid mail to the owners of the parts into which the parcel is divided. R.S.O. 1990, c. D.17, s. 65 (2).
Apportionment of assessment
(3) The engineer in making the apportionment shall have regard to the part of the parcel affected by the drainage works, and shall make the apportionment in writing and file it with the clerk of the local municipality who shall attach it to the original assessment and shall send, by prepaid mail, a copy thereof to each of such owners, and, subject to subsection (5), the apportionment is binding upon the lands assessed. R.S.O. 1990, c. D.17, s. 65 (3).
Costs
(4) The costs, including the fees of the engineer, shall be borne and paid by the parties in the manner fixed or apportioned by the engineer or, on appeal, by the Tribunal. R.S.O. 1990, c. D.17, s. 65 (4); 2006, c. 19, Sched. A, s. 6 (1).
Appeal of apportionment
(5) Any such owner who is dissatisfied with such apportionment and who is assessed for a sum greater than $500 may appeal to the Tribunal within forty days after the date a copy of the apportionment is sent to the owner by the clerk. R.S.O. 1990, c. D.17, s. 65 (5); 2006, c. 19, Sched. A, s. 6 (1).
Agreement on share of assessment
(6) When the owners of the subdivided land mutually agree on the share of the drainage assessment that each should pay, they may enter into a written agreement and file it with the clerk of the local municipality and, if the agreement is approved by the council by resolution, no engineer need be instructed under subsection (1). R.S.O. 1990, c. D.17, s. 65 (6).
Subsequent connections with drainage works
66. (1) Where an owner of land that is not assessed for a drainage works subsequently connects the land with the drainage works for the purpose of drainage or where the nature or extent of the use of a drainage works by land assessed for the drainage works is subsequently altered, an engineer appointed by the initiating municipality for the purpose shall make an inspection and assess the land for a just proportion of the drainage works, regard being had to any compensation paid to the owner of such land in respect of the drainage works, but no person shall connect such land to the drainage works without the approval of the council of the municipality. R.S.O. 1990, c. D.17, s. 66 (1).
Notice of assessment
(2) The clerk of the initiating municipality shall forthwith send a copy of the assessment to the owners of land assessed under subsection (1), and any owner who is so assessed for a sum greater than $500 and is dissatisfied with the assessment may appeal to the Tribunal within forty days after the date the notice is sent to the owner by the clerk. R.S.O. 1990, c. D.17, s. 66 (2); 2006, c. 19, Sched. A, s. 6 (1).
Use of amount collected
(3) The amount collected under subsection (1) shall be credited to the account of the drainage works and shall be used only for the improvement, maintenance or repair of the whole or any part of the drainage works. R.S.O. 1990, c. D.17, s. 66 (3).
Tenant’s covenant to pay taxes, when to include drainage assessments
67. Any agreement on the part of a tenant to pay the rates or taxes in respect of the demised land does not include the charges and assessments for a drainage works unless the agreement in express terms so provides, but, in cases of contract to purchase or of leases giving the lessee an option to purchase, the charges and assessments for a drainage works, in connection with which proceedings were commenced under this Act after the date of the contract or lease and which have already been paid by the owner, shall in the absence of any agreement to the contrary, be added to the price and shall be paid by the purchaser or the lessee where the purchaser or lessee exercises an option to purchase, but the amount still unpaid on the cost of the drainage works and charged against the lands shall be borne by the purchaser unless otherwise provided by the conveyance or agreement. R.S.O. 1990, c. D.17, s. 67.
Registration of by-law
68. Where compensation has been paid to the owner of any land under section 32 or 33, the clerk of the local municipality shall cause to be registered in the proper land registry office a copy of the by-law adopting the report, exclusive of the plans, profiles and specifications of the drainage works, together with a statement of the amount paid and a description of the land in respect of which the amount was paid in the form prescribed in the regulations. R.S.O. 1990, c. D.17, s. 68.
Public utility or road authority, option to construct drainage works
69. (1) Where a drainage works or a part thereof is to be constructed, improved, maintained or repaired upon, along, adjoining, under or across the lands, permanent way, transmission lines, power lines, wires, conduits or other permanent property of a public utility or road authority, the public utility or road authority may construct, improve, maintain or repair such drainage works or part. R.S.O. 1990, c. D.17, s. 69 (1).
Non-exercise by public utility or road authority
(2) Where the public utility or road authority does not exercise its powers under subsection (1) or does not complete such drainage works or part within a reasonable time and without unnecessary delay, such drainage works or part may be completed by the initiating municipality in the same manner as any other drainage works. R.S.O. 1990, c. D.17, s. 69 (2).
Fees of engineer part of cost
70. The fees and expenditures of the engineer form part of the cost of the drainage works. R.S.O. 1990, c. D.17, s. 70.
Account of engineer
71. The account of the engineer shall be set out in such detail as the council of the local municipality that appointed the engineer may require. R.S.O. 1990, c. D.17, s. 71.
Review by Tribunal
72. (1) The council of the local municipality, within forty days after the engineer’s account is presented to the clerk of the municipality, may, on notice to the engineer, apply to the Tribunal, which shall review the account and make any alteration it considers just. R.S.O. 1990, c. D.17, s. 72 (1); 2006, c. 19, Sched. A, s. 6 (7).
Appeal to referee
(2) Where the account as confirmed or altered by the Tribunal exceeds $1,000, either party may, on notice to the other party, appeal the decision of the Tribunal to the referee, whose decision is final. R.S.O. 1990, c. D.17, s. 72 (2); 2006, c. 19, Sched. A, s. 6 (1).
Non-requirement of notice
(3) In any application made under subsection (1), it shall not be necessary to notify all persons assessed for the drainage works. R.S.O. 1990, c. D.17, s. 72 (3).
Costs to be deemed part of cost of drainage works
73. (1) Except where otherwise provided in this Act or by a decision on an appeal, the cost of any application, reference or appeal and the cost of temporary financing for the construction, improvement, repair and maintenance of a drainage works, shall form part of the cost of the drainage works. R.S.O. 1990, c. D.17, s. 73 (1).
Cost of council meetings
(2) The cost of council meetings and special council meetings shall not be included in the cost of the drainage works. R.S.O. 1990, c. D.17, s. 73 (2).
Fees of clerk
(3) The council of a local municipality may by by-law provide for payment to the clerk of the municipality of reasonable fees or other remuneration for services performed by the clerk in carrying out the provisions of this Act, but such fees or other remuneration shall not be deemed to form part of the cost of the drainage works. R.S.O. 1990, c. D.17, s. 73 (3).
Maintenance, Repair and Improvement
Maintenance of drainage works and cost
74. Any drainage works constructed under a by-law passed under this Act or any predecessor of this Act, relating to the construction or improvement of a drainage works by local assessment, shall be maintained and repaired by each local municipality through which it passes, to the extent that such drainage works lies within the limits of such municipality, at the expense of all the upstream lands and roads in any way assessed for the construction or improvement of the drainage works and in the proportion determined by the then current by-law pertaining thereto until, in the case of each municipality, such provision for maintenance or repair is varied or otherwise determined by an engineer in a report or on appeal therefrom. R.S.O. 1990, c. D.17, s. 74.
Service of copy of by-law on municipality liable for contribution and appeal from by-law
75. (1) The council of any local municipality undertaking the repair of a drainage works without the report of an engineer, shall, before commencing the repairs,
(a) give two readings to a by-law for undertaking such repairs, which by-law shall recite the description, extent and estimated cost of the repairs to be done and the amount to be contributed therefor by each local municipality affected by the drainage works and shall be known as a provisional by-law; and
(b) serve upon the head or clerk of any municipality liable to contribute any portion of the cost of such repairs a copy of the provisional by-law,
and the council of any municipality so served may, within forty days thereafter, appeal from such by-law to the Tribunal on the ground that work provided for in the by-law is unnecessary or that such drainage works has never been completed through the default or neglect of the municipality whose duty it was to do the work. R.S.O. 1990, c. D.17, s. 75 (1); 2006, c. 19, Sched. A, s. 6 (8).
Council to furnish amount required
(2) The council of every municipality served with a copy of the provisional by-law shall, forthwith after the time for appealing from such by-law has expired and there are no appeals or after all appeals have been decided, pass a by-law to raise the amount assessed against lands and roads in the municipality, as stated in the provisional by-law or as determined on appeal therefrom, and shall pay over such amount within a reasonable time to the treasurer of the initiating municipality. R.S.O. 1990, c. D.17, s. 75 (2).
When levy for maintenance required
(3) The council of any municipality shall not be required to assess and levy the amount charged for maintenance or repair of a drainage works more than once in every five years if the total expense incurred does not exceed the sum of $5,000, in which case sections 65 and 66 of the Ontario Municipal Board Act do not apply. R.S.O. 1990, c. D.17, s. 75 (3).
Varying original assessments for maintenance
76. (1) The council of any local municipality liable for contribution to a drainage works in connection with which conditions have changed or circumstances have arisen such as to justify a variation of the assessment for maintenance and repair of the drainage works may make an application to the Tribunal, of which notice has been given to the head of every other municipality affected by the drainage works, for permission to procure a report of an engineer to vary the assessment, and, in the event of such permission being given, such council may appoint an engineer for such purpose and may adopt the report but, if all the lands and roads assessed or intended to be assessed lie within the limits of one local municipality, the council of that municipality may procure and adopt such report without such permission. R.S.O. 1990, c. D.17, s. 76 (1); 2006, c. 19, Sched. A, s. 6 (1).
Proceedings on report of engineer
(2) The proceedings upon such report, excepting appeals, shall be the same, as nearly as may be, as upon the report for the construction of the drainage works. R.S.O. 1990, c. D.17, s. 76 (2).
Appeal from report of engineer
(3) Any council served with a copy of such report may, within forty days of such service, appeal to the Tribunal from the finding of the engineer as to the portion of the cost of the drainage works for which the municipality is liable. R.S.O. 1990, c. D.17, s. 76 (3); 2006, c. 19, Sched. A, s. 6 (1).
Appeal from assessment
(4) Any owner of land assessed for maintenance or repair may appeal from the assessment in the report on the grounds and in the manner provided by section 52 in the case of the construction of the drainage works. R.S.O. 1990, c. D.17, s. 76 (4).
Basis of future assessments
(5) An assessment determined under this section shall thereafter, until it is further varied, form the basis of any assessment for maintenance or repair of the drainage works affected thereby. R.S.O. 1990, c. D.17, s. 76 (5).
Deepening, widening or extending without report of engineer
77. (1) The council of any local municipality whose duty it is to maintain and repair a drainage works for which only lands and roads within or under the jurisdiction of the municipality are assessed may, after the completion of the drainage works, without the report of an engineer, upon a proportional assessment on the lands and roads as last assessed for the construction, maintenance or repair of the drainage works, make improvements thereto by deepening, widening or extending the drainage works to an outlet, provided the cost of such deepening, widening or extending is not more than $4,500, but the amount expended may be increased to 20 per cent of the initial cost of the drainage works upon receiving approval as set out in the requirements for a petition of those parties eligible to sign a petition under section 4. R.S.O. 1990, c. D.17, s. 77 (1).
Moving drainage works off road
(2) Where any road authority desires to relocate a drainage works or part thereof that is on or adjacent to a road under its jurisdiction, upon the report of an engineer appointed by the municipality whose duty it is to maintain and repair the drainage works that the drainage works or part thereof can be moved to a specified new location without impairing the capacity or efficiency of such drainage works or adversely affecting any person or property, the council of a local municipality may authorize such relocation within the boundaries of the municipality at the expense of the road authority. R.S.O. 1990, c. D.17, s. 77 (2).
Written opinion in lieu of report
(3) Where the relocation of a drainage works or part thereof referred to in subsection (2) is to be effected within the lands under the jurisdiction of the road authority, the engineer may prepare a written opinion instead of a report. R.S.O. 1990, c. D.17, s. 77 (3).
Improving, upon examination and report of engineer
78. (1) Where, for the better use, maintenance or repair of any drainage works constructed under a by-law passed under this Act or any predecessor of this Act, or of lands or roads, it is considered expedient to change the course of the drainage works, or to make a new outlet for the whole or any part of the drainage works, or to construct a tile drain under the bed of the whole or any part of the drainage works as ancillary thereto, or to construct, reconstruct or extend embankments, walls, dykes, dams, reservoirs, bridges, pumping stations and other protective works as ancillary to the drainage works, or to otherwise improve, extend to an outlet or alter the drainage works or to cover the whole or any part of it, or to consolidate two or more drainage works, the council of any municipality whose duty it is to maintain and repair the drainage works or any part thereof may, without the petition required in section 4 but on the report of an engineer appointed by it, undertake and complete the drainage works as set forth in such report. R.S.O. 1990, c. D.17, s. 78 (1).
Notice to conservation authority
(2) An engineer shall not be appointed under subsection (1) until thirty days after a notice advising of the proposed drainage works has been sent by prepaid mail to the secretary-treasurer of each conservation authority that has jurisdiction over any of the lands that would be affected. R.S.O. 1990, c. D.17, s. 78 (2).
Powers and duties of engineer
(3) The engineer has all the powers and shall perform all the duties of an engineer appointed with respect to the construction of a drainage works under this Act. R.S.O. 1990, c. D.17, s. 78 (3).
Proceedings
(4) All proceedings, including appeals, under this section shall be the same as on a report for the construction of a drainage works. R.S.O. 1990, c. D.17, s. 78 (4).
Power to compel repairs
79. (1) Upon forty-five days notice in writing served by any person affected by the condition of a drainage works, upon the head or clerk of the local municipality whose duty it is to maintain and repair the drainage works, the municipality is compellable by an order of the referee to exercise the powers and to perform the duties conferred or imposed upon it by this Act as to maintenance and repair or such of the powers and duties as to the referee appears proper, and the municipality is liable in damages to the owner whose property is so injuriously affected. R.S.O. 1990, c. D.17, s. 79 (1).
Municipality liable for damages caused by non-repair
(2) Despite subsection (1), the local municipality whose duty it is to maintain and repair drainage works shall not become liable in damages to any person affected by reason of the non-repair of the drainage works until after service by or on behalf of such person of the notice referred to in subsection (1) upon the head or clerk of the municipality, describing with reasonable certainty the alleged lack of maintenance and repair of the drainage works. R.S.O. 1990, c. D.17, s. 79 (2).
No liability where drainage works blocked by ice or snow
(3) The local municipality whose duty it is to maintain and repair a drainage works is not liable in damages for any injury caused by reason of a drainage works being blocked by snow or ice and overflowing the lands of any person without negligence on the part of the municipal corporation. R.S.O. 1990, c. D.17, s. 79 (3).
Person responsible for obstruction to remove it on notice
80. (1) When a drainage works becomes obstructed by a dam, low bridge, fence, washing out of a private drain, or other obstruction, for which the owner or occupant of the land adjoining the drainage works is responsible, so that the free flow of the water is impeded thereby, the persons owning or occupying the land shall, upon reasonable notice in writing given by the council of the local municipality whose duty it is to maintain and repair the drainage works or by a drainage superintendent appointed by the council, remove such obstruction and, if it is not so removed within the time specified in the notice, the council or the drainage superintendent shall forthwith cause it to be removed, and the cost thereof is payable to the municipality by the owner or occupant of the land. R.S.O. 1990, c. D.17, s. 80 (1); 1998, c. 18, Sched. A, s. 1 (4).
Collection of cost of removal
(2) If the cost of removing the obstruction is not paid to the local municipality by the owner or occupant of the land forthwith after the completion of the work, the council may pay the cost, and the clerk of the municipality shall place the amount of cost upon the collector’s roll against such land and such amount shall be collected in the same manner as real property taxes. R.S.O. 1990, c. D.17, s. 80 (2).
Removal of minor obstructions
81. The council by by-law or resolution shall direct a drainage superintendent to remove from any drainage works all weeds and brushwood, fallen timber or other minor obstructions for which the owner or occupant of the lands adjacent to the drainage works may not be responsible, and the cost of such work is chargeable as part of the cost of maintenance of the drainage works. R.S.O. 1990, c. D.17, s. 81; 1998, c. 18, Sched. A, s. 1 (5).
Municipality may sue for cost of damage to drainage works
82. (1) A municipality in which a drainage works or part thereof is situate may bring an action for damages against any person who destroys or injures in any way a drainage works, including any bench mark or permanent level, and any damages ordered by the referee to be paid shall be paid to the municipality and used for the construction, improvement, maintenance or repair of the drainage works. R.S.O. 1990, c. D.17, s. 82 (1).
Penalty for damage to drainage works
(2) Every person who obstructs, fills up or injures or destroys by any means a drainage works is guilty of an offence and on conviction, in addition to liability in damages, is liable to a fine of not more than $1,000 or to imprisonment for a term of not more than thirty days, or to both. R.S.O. 1990, c. D.17, s. 82 (2).
Pollution of drains prohibited
83. (1) Except as authorized by a by-law of the initiating municipality approved by the Ministry of the Environment, no person shall discharge or deposit or permit to be discharged or deposited into any drainage works any liquid, material or substance other than unpolluted drainage water. R.S.O. 1990, c. D.17, s. 83 (1).
Penalty for pollution
(2) Every person who contravenes subsection (1) is guilty of an offence and on conviction is liable to a fine of not more than $1,000. R.S.O. 1990, c. D.17, s. 83 (2).
Abandonment of all or part of drainage works
84. (1) Upon the written request of three-quarters of the owners of land assessed for benefit in respect of a drainage works, who, according to the last revised assessment roll, own not less than three-quarters of the area assessed for benefit as shown in the by-law or by-laws under which the drainage works exist, asking for the abandonment of such drainage works or a part thereof, the council of the initiating municipality shall forthwith notify all owners of land assessed for the drainage works by prepaid mail, at their addresses as shown in the last revised assessment roll, of its intention to abandon such drainage works, or such part thereof as is specified in the notice, unless any owner within ten days of the mailing of such notice, gives to the clerk of the municipality written notice that the owner requires a report of an engineer to be made on such proposed abandonment. R.S.O. 1990, c. D.17, s. 84 (1).
Idem
(2) The council of the initiating municipality may give notice as in subsection (1) of its intention to abandon a drainage works or such part thereof as is specified in the notice without any written request. R.S.O. 1990, c. D.17, s. 84 (2).
Engineer’s report may be required
(3) If, within such period of ten days, any owner notifies the clerk, the council shall appoint an engineer to examine the drainage works and report recommendations as to the proposed abandonment, any necessary work in connection therewith, the sale of any assets, the cost of abandonment and all other appropriate matters and shall assess all costs, including the engineer’s compensation, and damage allowances against persons liable to assessment in connection with the drainage works in such proportions as appear just. R.S.O. 1990, c. D.17, s. 84 (3).
Procedures on report
(4) All proceedings, including appeals, with respect to a report under subsection (1) shall be the same with necessary modifications as on a report for the construction of a drainage works. R.S.O. 1990, c. D.17, s. 84 (4).
Abandonment by council
(5) If no notice is mailed to the clerk in accordance with subsection (1) or if the engineer’s report, as it may be altered on appeal, recommends the abandonment of the drainage works, the council may by by-law abandon the drainage works, and thereafter the municipality has no further obligation with respect to the drainage works. R.S.O. 1990, c. D.17, s. 84 (5).
Disbursement of remaining funds
(6) Any money remaining to the credit of the drainage works after it is abandoned shall be divided proportionately among the owners of lands and roads assessed therefor. R.S.O. 1990, c. D.17, s. 84 (6).
Provincial grants
85. Grants may be made in respect of,
(a) assessments made under this Act upon lands used for agricultural purposes,
(i) for drainage works undertaken in accordance with section 4, 74 or 78 where a report of an engineer describing the current work has been adopted in accordance with this Act, and
(ii) for maintenance, repair and minor improvements undertaken on the recommendation of a drainage superintendent within the budgeting limitations established by the Minister for that municipality;
(b) costs incurred by the municipality in the employment of drainage superintendents; and
(c) the total cost of preparing a preliminary report exclusive of the cost of preparing any benefit cost statement and any environmental appraisal. R.S.O. 1990, c. D.17, s. 85; 1998, c. 18, Sched. A, s. 1 (6, 7).
When grants not to be made
86. (1) Subject to subsection (2), grants shall not be made in respect of assessments made under this Act upon lands owned by Canada, Ontario or a municipality or in respect of the assessment of the cost of lateral drains. R.S.O. 1990, c. D.17, s. 86 (1).
Exception
(2) Grants may be made in respect of lands owned by Ontario and leased for agricultural purposes to a lessee with an option to purchase. R.S.O. 1990, c. D.17, s. 86 (2).
Payment of grant
87. (1) The Minister, upon receipt of a completed application form, may pay to the treasurer of an initiating municipality a grant of,
(a) 33 ⅓ per cent of the assessments eligible for a grant under section 85, if the drainage works is in a local municipality that is not within a territorial district; or
(b) 66 ⅔ per cent of the assessments eligible for a grant under section 85, if the drainage works is in a local municipality within a territorial district. 2002, c. 17, Sched. F, Table.
Grants in unorganized territory
(2) Where a drainage works is in territory without municipal organization, an amount not exceeding 80 per cent of the assessments eligible for a grant under section 85 in respect of such drainage works may be paid by the Minister out of the money appropriated therefor by the Legislature. R.S.O. 1990, c. D.17, s. 87 (2).
Where drainage superintendents employed
(3) Where one or more municipalities employ drainage superintendents who have qualifications satisfactory to the Minister, the Minister may direct that 50 per cent of the costs incurred by the municipality or municipalities in the employment of the superintendents shall be paid out of the money appropriated for that purpose by the Legislature. 1998, c. 18, Sched. A, s. 1 (8).
Application for grant
88. (1) Upon the practical completion of the drainage works and after the time for appealing against assessments has expired and there are no appeals or after all appeals against assessments have been decided, the council of the initiating municipality shall forward to the Director an application for a grant in such form as is provided by the Director. R.S.O. 1990, c. D.17, s. 88 (1).
Grant re interest charges
(2) No grant shall be paid in respect of interest charges on any drainage works accruing after 120 days from the completion thereof as certified by the engineer or a drainage superintendent. R.S.O. 1990, c. D.17, s. 88 (2); 1998, c. 18, Sched. A, s. 1 (9).
Distribution
89. (1) Where the drainage works is in two or more municipalities, the grant shall be distributed by the treasurer of the initiating municipality among all such municipalities in the proportion that the total of the assessments eligible for a grant in each municipality bears to the total of all assessments eligible for a grant in all of the municipalities. R.S.O. 1990, c. D.17, s. 89 (1).
Grant to be applied to reduce assessments
(2) The treasurer of each municipality shall apply the amount of the grant received by that municipality to reduce the assessment on each parcel of land in the municipality eligible for a grant in the proportion that each such assessment bears to the total of the assessments eligible for a grant in the municipality. R.S.O. 1990, c. D.17, s. 89 (2).
Reduction of grant
90. The Minister may reduce or withhold a grant on any drainage works if in his or her opinion the costs other than the contract price are excessive. R.S.O. 1990, c. D.17, s. 90.
Director
91. The Minister may appoint a Director for the purposes of this Act. R.S.O. 1990, c. D.17, s. 91.
Persons to advise and assist
92. The Minister may designate such persons as he or she considers necessary to advise and assist municipalities and engineers in the application and administration of this Act and any such person who is not a public servant employed under Part III of the Public Service of Ontario Act, 2006 shall be paid such remuneration as the Lieutenant Governor in Council may determine, together with reasonable expenses. R.S.O. 1990, c. D.17, s. 92; 2006, c. 35, Sched. C, s. 27.
Drainage Superintendent and Commissioners
Appointment of drainage superintendent
93. (1) The council of a local municipality may by by-law appoint a drainage superintendent,
(a) to initiate and supervise the maintenance and repair of any drainage works;
(b) to assist in the construction or improvement of any drainage works; and
(c) to report to the council on the superintendent’s activities mentioned in clauses (a) and (b). 1998, c. 18, Sched. A, s. 1 (10).
More than one drainage superintendent
(1.1) The council of a local municipality may, with the approval of the Minister, appoint more than one drainage superintendent under subsection (1). 1998, c. 18, Sched. A, s. 1 (10).
Remuneration
(1.2) The council may provide for fees or other remuneration for services performed by drainage superintendents in carrying out the provisions of this Act, but the fees or other remuneration shall not be deemed to form part of the cost of the drainage works, and shall be paid from the general funds of the municipality. 1998, c. 18, Sched. A, s. 1 (10).
Commissioner may be appointed
(2) Where no drainage superintendent is appointed under this section, the council may by by-law appoint one or more commissioners,
(a) to assist the engineer in the construction or improvement of a drainage works; and
(b) to supervise the maintenance of any drainage works,
and to report thereon to council and may provide for fees or other remuneration for services performed by a commissioner under this subsection, but such fees or other remuneration shall not be deemed to form part of the cost of the drainage works, and shall be paid from the general funds of the municipality. R.S.O. 1990, c. D.17, s. 93 (2); 1998, c. 18, Sched. A, s. 1 (11).
Inspection of drainage works
94. (1) The drainage superintendents appointed by the council of a local municipality shall inspect every drainage works for which the municipality is responsible and shall report periodically to council on the condition of the drainage works in the municipality. 1998, c. 18, Sched. A, s. 1 (12).
Drainage superintendent may act for more than one municipality
(2) Two or more municipalities may appoint the same person to be a drainage superintendent within each municipality. R.S.O. 1990, c. D.17, s. 94 (2); 1998, c. 18, Sched. A, s. 1 (13).
Appointment of commissioner
95. (1) For the better maintenance and repair of drainage works by embanking, pumping or other mechanical operations, the council of the municipality initiating the drainage works may by by-law,
(a) appoint one or more commissioners with power to,
(i) enter into all necessary and proper contracts for the purchase of fuel, erection or repairs of buildings and purchase and repairs of machinery, and
(ii) do all other things necessary for successfully operating the drainage works and for keeping the embankment thereof in repair as may be set forth in the by-law appointing the commissioner or commissioners; and
(b) provide for defraying the annual cost of maintaining and operating the drainage works by assessment upon the lands and roads in any way liable to assessment therefor. R.S.O. 1990, c. D.17, s. 95 (1).
Fees, etc.
(2) The fees or other remuneration of a commissioner shall form part of the cost of the maintenance and repair of the drainage works. R.S.O. 1990, c. D.17, s. 95 (2).
Powers
(3) A drainage superintendent and a commissioner have the same powers as to entry on land as are given to the engineer and the engineer’s assistants under subsection 12 (1). 1998, c. 18, Sched. A, s. 1 (14).
Offence
96. Every person who wilfully interferes with or obstructs a drainage superintendent or a commissioner in the exercise of his or her powers under this Act is guilty of an offence and on conviction is liable to a fine of not more than $2,000. R.S.O. 1990, c. D.17, s. 96.
Court of revision
97. (1) Subject to subsections (3), (4) and (5), a court of revision shall consist of three or five members appointed by the council of the initiating municipality and such members other than members of the council may be paid such remuneration and expenses as the council may by by-law provide. R.S.O. 1990, c. D.17, s. 97 (1).
Qualification
(2) Every such member shall be a person eligible to be elected a member of council or shall be a member of council. R.S.O. 1990, c. D.17, s. 97 (2).
Where more than one municipality
(3) Where the lands assessed for the drainage works extend from the initiating municipality into a neighbouring municipality, the court of revision shall consist of two members appointed by the council of the initiating municipality, of whom one shall be chair and one member appointed by the council of each of the neighbouring municipalities and the court shall hear and rule on appeals as if the entire area affected by the drainage works were in one municipality. R.S.O. 1990, c. D.17, s. 97 (3).
Quorum
(4) A majority of the members of the court of revision shall constitute and, despite the decision of any court, shall be deemed always to have constituted a quorum. R.S.O. 1990, c. D.17, s. 97 (4).
Jurisdiction and powers of quorum
(5) A quorum of the court of revision is sufficient and, despite the decision of any court, shall be deemed always to have been sufficient to exercise all of the jurisdiction and powers of the court of revision. R.S.O. 1990, c. D.17, s. 97 (5).
Tribunal
98. (1)-(3) Repealed: 1999, c. 12, Sched. A, s. 9 (3).
Proceedings of Tribunal
(4) The Tribunal may,
(a) hold sittings at any place in Ontario and in more than one place at the same time; and
(b) procure reports from engineers and other professional persons in order to assist the Tribunal in reaching a decision. R.S.O. 1990, c. D.17, s. 98 (4); 2006, c. 19, Sched. A, s. 6 (1); 2006, c. 19, Sched. A, s. 6 (9).
(5) Repealed: 1999, c. 12, Sched. A, s. 9 (3).
Clerk of Tribunal
(6) The clerk of the initiating municipality shall be the clerk of the Tribunal. R.S.O. 1990, c. D.17, s. 98 (6); 2006, c. 19, Sched. A, s. 6 (1).
Stenographic reporters
(7) The Tribunal may from time to time employ stenographic reporters to report hearings before the Tribunal and may fix their fees and such fees shall be included in the costs of the hearing and shall be borne and paid as the Tribunal may direct. R.S.O. 1990, c. D.17, s. 98 (7); 2006, c. 19, Sched. A, s. 6 (10).
Sittings of Tribunal
(8) Where the sittings of the Tribunal are to be held in a municipality, the municipality shall provide a suitable room for holding a hearing. R.S.O. 1990, c. D.17, s. 98 (8); 2006, c. 19, Sched. A, s. 6 (1).
Copy of decision
(9) The Tribunal shall send by registered mail addressed to the parties to any proceedings who took part in the hearing, at their addresses last known to the Tribunal and to the Minister, a copy of its final decision and order, if any, in the proceedings. R.S.O. 1990, c. D.17, s. 98 (9); 2006, c. 19, Sched. A, s. 6 (1).
Costs, payment of
(10) The costs of any proceedings before the Tribunal shall be paid by or apportioned between the parties in such manner as the Tribunal considers proper, and where costs are ordered to be paid, the order for payment thereof may be filed in the Small Claims Court and is enforceable as a judgment or order of that court. R.S.O. 1990, c. D.17, s. 98 (10); 2006, c. 19, Sched. A, s. 6 (11).
What costs chargeable
(11) The costs chargeable or to be awarded in any proceedings may include the costs of witnesses and of procuring their attendance, the costs of secretarial staff and such other costs as the Tribunal may direct. R.S.O. 1990, c. D.17, s. 98 (11); 2006, c. 19, Sched. A, s. 6 (1).
Proceeding commenced by notice
99. In any application, appeal or reference to the Tribunal, the action shall be commenced by serving notice upon the council of the initiating municipality and the clerk shall forthwith record the notice and except as otherwise provided send a copy of the notice to the Tribunal and to all persons assessed for the drainage works. R.S.O. 1990, c. D.17, s. 99; 2006, c. 19, Sched. A, s. 6 (1).
Extension of time
100. The Tribunal, in any case that it considers proper, may extend the time otherwise limited for application, appeal or reference. R.S.O. 1990, c. D.17, s. 100; 2006, c. 19, Sched. A, s. 6 (12).
Decision final
101. In any application, appeal or reference under sections 8, 10, 48, 49, 50, 54, 64, 65, 66 and 75 the decision of the Tribunal is final. R.S.O. 1990, c. D.17, s. 101; 2006, c. 19, Sched. A, s. 6 (1).
Appointment of referee
102. (1) The Lieutenant Governor in Council may appoint a referee for the purposes of this Act. R.S.O. 1990, c. D.17, s. 102 (1).
Acting referee
(2) The Lieutenant Governor in Council from time to time may appoint an acting referee or referees for the purposes of this Act, and an acting referee has the same powers and duties as the referee. R.S.O. 1990, c. D.17, s. 102 (2).
Qualifications of referee
(3) The referee or an acting referee shall be a judge of the Superior Court of Justice or a barrister of at least ten years standing at the bar of Ontario. R.S.O. 1990, c. D.17, s. 102 (3); 2001, c. 9, Sched. A, s. 1.
Remuneration
(4) Despite any other Act, the referee or an acting referee shall be paid such remuneration as the Lieutenant Governor in Council may determine, together with his or her reasonable expenses and expenses for secretarial services. R.S.O. 1990, c. D.17, s. 102 (4).
Referee not to practise under Act
(5) No referee or acting referee shall practise as a solicitor or barrister in any matter arising under this Act or act as legal agent or adviser in any such matter. R.S.O. 1990, c. D.17, s. 102 (5).
Notice of time and place of hearing
103. (1) Where an application or appeal is made to the referee, he or she shall give an appointment to the parties to proceed therewith at such place and time and in such manner as to him or her may seem proper, but, unless the parties otherwise consent, a hearing shall be in the upper-tier municipality or single-tier municipality in which the drainage works is or is to be situate. R.S.O. 1990, c. D.17, s. 103 (1); 2002, c. 17, Sched. F, Table.
Part of works
(1.1) If only part of the drainage works is or is to be situate in an upper-tier municipality or single-tier municipality, the hearing shall be held in an upper-tier municipality or a single-tier municipality in which any part is or is to be situate. 2002, c. 17, Sched. F, Table.
Interpretation
(1.2) In subsections (1) and (1.1), a single-tier municipality does not include a single-tier municipality within a territorial district or within an upper-tier municipality and an upper-tier municipality includes a territorial district. 2002, c. 17, Sched. F, Table.
Use of court house, etc.
(2) When an appointment is given by the referee for a hearing in any municipality where a court house is situate, he or she has in all respects the same authority as a judge of the Superior Court of Justice with respect to the use of the court house or other place or apartments therein. R.S.O. 1990, c. D.17, s. 103 (2); 2001, c. 9, Sched. A, s. 1.
Clerk of court
104. (1) The local registrar of the Superior Court of Justice shall be the clerk of the court of the referee and shall take charge of and file all the exhibits, and is entitled to the same fees for filings and for his or her services and for certified copies of decisions or reports as for similar services in the Superior Court of Justice. R.S.O. 1990, c. D.17, s. 104 (1); 2001, c. 9, Sched. A, s. 1.
Acting clerk
(2) In the absence of the local registrar of the Superior Court of Justice, the referee may appoint some other person to act as clerk of the court of the referee for the purpose of the trial and for taking charge of and filing all exhibits, and the person so appointed while so acting has the same power as the local registrar of the Superior Court of Justice and is entitled to such fees as the referee may direct for his or her attendance at the court, and such fees shall be included in the costs and shall be borne and paid as the referee may direct. R.S.O. 1990, c. D.17, s. 104 (2); 2001, c. 9, Sched. A, s. 1.
Stenographic reporters
(3) The referee may from time to time employ stenographic reporters to report hearings and trials before the referee and fix their fees, and such fees shall be included in the costs and shall be borne and paid as the referee may direct. R.S.O. 1990, c. D.17, s. 104 (3).
Sheriffs, etc., to assist referee
105. Sheriffs, deputy sheriffs, constables and other peace officers shall aid, assist and obey the referee in the exercise of the jurisdiction conferred by this Act whenever required so to do, and shall, upon the certificates of the referee, be paid such fees as they are entitled to for similar services at the sittings of the Superior Court of Justice for the trial of causes. R.S.O. 1990, c. D.17, s. 105; 2001, c. 9, Sched. A, s. 1.
Powers of referee
106. (1) The referee has original jurisdiction,
(a) to entertain any appeal with respect to the report of the engineer under section 47;
(b) to determine the validity of, or to confirm, set aside or amend any petition, resolution of a council, provisional by-law or by-law relating to a drainage works under this Act or a predecessor of this Act;
(c) to determine claims and disputes arising under this Act, including, subject to section 120, claims for damages with respect to anything done or purporting to have been done under this Act or a predecessor of this Act or consequent thereon;
(d) to entertain applications for orders directing to be done anything required to be done under this Act;
(e) to entertain applications for orders restraining anything proposed or purporting to be done under this Act or a predecessor of this Act; and
(f) over any other matter or thing in relation to which application may be made to him or her under this Act. R.S.O. 1990, c. D.17, s. 106 (1).
Jurisdiction of referee
(2) Subject to section 101, the referee has jurisdiction to hear appeals from any decision or order of the Tribunal and for such purpose may make any order that the Tribunal might have made and may substitute his or her opinion for that of the Tribunal. R.S.O. 1990, c. D.17, s. 106 (2); 2006, c. 19, Sched. A, s. 6 (1).
Idem
(3) The referee has jurisdiction to entertain and dispose of any interlocutory application relating to any matter otherwise within his or her jurisdiction and his or her order thereon is final. R.S.O. 1990, c. D.17, s. 106 (3).
Determination of questions of fact or law
(4) The referee has power to determine all questions of fact or law that it is necessary to determine for the purpose of disposing of any matter within his or her jurisdiction and to make such decision, order or direction as may be necessary for such purpose. R.S.O. 1990, c. D.17, s. 106 (4).
Referee may make rules
107. (1) The referee may, with the approval of the Lieutenant Governor in Council, make rules regulating the practice and procedure to be followed in all proceedings before him under this Act and may prescribe tariffs and fees therefor. R.S.O. 1990, c. D.17, s. 107 (1).
Referee may give directions
(2) The referee may give directions relating to the conduct of proceedings before him or her and as to the persons who shall be parties to such proceedings. R.S.O. 1990, c. D.17, s. 107 (2).
Assessment of costs
108. Costs shall be assessed by the referee, or he or she may direct the assessment thereof by the local registrar of the Superior Court of Justice with whom the papers are filed or by an assessment officer. R.S.O. 1990, c. D.17, s. 108; 2001, c. 9, Sched. A, s. 1.
Costs in discretion of referee
109. The costs of any proceedings before the referee are in the discretion of the referee. R.S.O. 1990, c. D.17, s. 109.
Tariff of costs
110. In the absence of other provisions, the tariff of costs in any application or proceeding under this Act shall be that of the court that would have jurisdiction to try a civil action involving a similar amount of money or type of proceeding. R.S.O. 1990, c. D.17, s. 110.
Proceedings instituted by notice
111. (1) Proceedings for the determination of claims and disputes and for the recovery of damages, or for an order directing or restraining the doing of any act or thing shall be instituted by serving ten clear days notice setting forth the grounds of the claim upon all persons concerned. R.S.O. 1990, c. D.17, s. 111 (1).
Notice filed in Superior Court of Justice
(2) A copy of the notice with an affidavit of service thereof shall be filed with the local registrar of the Superior Court of Justice for the area in which the initiating municipality is situate, and the notice shall be filed and served within two years from the time the cause of complaint arose. R.S.O. 1990, c. D.17, s. 111 (2); 2001, c. 9, Sched. A, s. 1.
Affidavits filed before motion
112. All affidavits intended to be used in support of a motion shall be filed with the local registrar of the Superior Court of Justice not fewer than five days before the return day of the motion. R.S.O. 1990, c. D.17, s. 112; 2001, c. 9, Sched. A, s. 1.
Extension of time for appeal
113. The referee may, where he or she considers it proper, extend the time otherwise limited for appeals or other proceedings. R.S.O. 1990, c. D.17, s. 113.
When referee proceeds on view
114. When the referee proceeds partly on view or on any special knowledge or skill possessed by him or her, he or she shall put in writing a statement thereof sufficiently full to allow the Divisional Court to form a judgment of the weight that should be given thereto, and he or she shall state as part of his or her reasons the effect given by him or her to such statement. R.S.O. 1990, c. D.17, s. 114.
Clerk to forward notice of filing
115. The decision of the referee, with the evidence, exhibits and statement, if any, of inspection or of technical knowledge and the reason for his or her decision, shall be filed in the office of the local registrar of the Superior Court of Justice for the area in which the initiating municipality is situate, and notice of the filing shall forthwith be given by the clerk, by prepaid mail, to the solicitors of the parties appearing by solicitor and to the other parties not represented by a solicitor, and also to the clerk of each municipality affected. R.S.O. 1990, c. D.17, s. 115; 2001, c. 9, Sched. A, s. 1.
Copy of decision to be sent to Minister and municipality
116. A copy of the decision certified by the referee or clerk of the court shall be sent or delivered,
(a) to the Minister without charge; and
(b) to the clerk of every municipality interested in the drainage works in question upon receipt of the sum chargeable therefor. R.S.O. 1990, c. D.17, s. 116.
Amendment of by-law
117. The provisional by-law or the by-law of the initiating municipality and of any other municipality interested shall be amended so as to incorporate and carry into effect the decision of the referee or such decision as varied on appeal, as the case may be. R.S.O. 1990, c. D.17, s. 117.
Assessing of costs payable
118. (1) Except as provided by subsections (2), (3) and (4), all damages and costs payable by a municipality and arising from proceedings taken under this Act shall be levied upon the lands and roads in any way assessed for the drainage works for construction, improvement, maintenance or repair in such manner as the referee or court may determine, and may be assessed, levied and collected in the same manner as rates assessed, levied and collected for maintenance under this Act. R.S.O. 1990, c. D.17, s. 118 (1).
Municipality in default to pay costs
(2) Where such damages and costs become payable owing to any improper action, neglect, default or omission on the part of the council of any municipality or of any of its officers or employees in the construction, improvement, maintenance or repair of the drainage works or in carrying out the provisions of this Act, the referee or court may direct that the whole or any part of such damages and costs shall be borne by the municipality and be payable out of the general funds thereof. R.S.O. 1990, c. D.17, s. 118 (2).
In cases of settlement
(3) Where in any such proceedings by or against a municipality a settlement is made, the damages and costs payable under the terms of the settlement by any municipality shall be borne and paid as directed by the referee or court, and in making such direction, the referee or court shall have regard to the provisions of subsection (2). R.S.O. 1990, c. D.17, s. 118 (3).
Where extension of drainage works necessary
(4) Where, in the opinion of the referee or court, damages and costs have become payable by reason of the insufficiency of the capacity or outlet of a drainage works and it is necessary in order to prevent a continuance of such damage to improve the drainage works, the referee or court may permit the council of the municipality to add such damages and costs to the engineer’s estimate of the cost of any such improvement. R.S.O. 1990, c. D.17, s. 118 (4).
Transfer to other court
119. Where an action is brought or is pending before the court of revision or the Tribunal or the referee and the matter should properly be heard by one of the other tribunals, the action may be transferred to the other tribunal without invalidating the proceedings provided the action was launched within the time limits prescribed in this Act. R.S.O. 1990, c. D.17, s. 119; 2006, c. 19, Sched. A, s. 6 (1).
Actions may be transferred to referee
120. (1) Where an action is brought or is pending and the court in which the action is brought or is pending or a judge thereof is of opinion that the relief sought therein is properly the subject of a proceeding under this Act or that it may be more conveniently tried before and disposed of by the referee, the court or judge may, on the application of either party, at any stage of the action make an order transferring it to the referee on such terms as appear just, and the referee shall thereafter give directions for the continuance of the action before him or her. R.S.O. 1990, c. D.17, s. 120 (1).
Limitation
(2) This section applies only where the action is brought within the period limited by this Act for taking proceedings on notice. R.S.O. 1990, c. D.17, s. 120 (2).
Appeal from decision of referee
121. Except as otherwise provided in this Act, the decision of the referee or acting referee may be appealed to the Divisional Court within thirty days after the filing thereof with the local registrar of the Superior Court of Justice or within such further time as the referee or Divisional Court may allow. R.S.O. 1990, c. D.17, s. 121; 2001, c. 9, Sched. A, s. 1.
Interprovincial drainage works, from Ontario into adjoining province
122. (1) Where it is considered necessary or expedient to extend a drainage works constructed under this Act from Ontario into or through lands in an adjoining province, or to extend a drainage works from an adjoining province into or through lands in Ontario, the Lieutenant Governor in Council may authorize the Minister to enter into an agreement with a designated officer of the adjoining province as to the proportion of the cost of any drainage works in the adjoining province to be borne and paid by Ontario and as to the proportion of the cost of any drainage works in Ontario to be borne and paid by the adjoining province. R.S.O. 1990, c. D.17, s. 122 (1).
Apportionment of cost
(2) Where such a drainage works extends from Ontario into or through lands in an adjoining province, the Minister may order a local municipality in Ontario in which the lands affected by the drainage works are situate to provide funds to pay for the proportion of the cost of the drainage works in the adjoining province to be borne and paid by Ontario, and thereupon this Act applies with necessary modifications to such drainage works. R.S.O. 1990, c. D.17, s. 122 (2).
Extension of drainage works from adjoining province
(3) Where a drainage works extends from an adjoining province into or through lands in Ontario, the Minister may order a local municipality into which the drainage works extends to provide for the construction of the necessary drainage works, and thereupon this Act applies with necessary modifications to such drainage works, and the contribution to the drainage works from the other province shall be paid to such local municipality on the completion of the drainage works. R.S.O. 1990, c. D.17, s. 122 (3).
Initiation of drainage works in unorganized territory
123. The Minister in his or her discretion and from time to time may prescribe the manner in which a drainage works shall be initiated and carried out in territory without municipal organization and the manner in which and the terms and conditions under which grants may be made. R.S.O. 1990, c. D.17, s. 123.
Authorization of emergency work
124. Where the Minister declares that an emergency exists, the council of a municipality may authorize emergency work under this Act before obtaining and adopting an engineer’s report. R.S.O. 1990, c. D.17, s. 124.
Regulations
125. The Lieutenant Governor in Council may make regulations prescribing forms and providing for their use. R.S.O. 1990, c. D.17, s. 125.